SPI SPI Energy Company Ltd

ITEM 1A. Risk Factors

Our business, financial condition and results of operations are subject to various changing business, competitive, economic, political and social conditions worldwide. In addition to the factors discussed elsewhere in this annual report, the following are some of the important factors that could adversely affect our operating results, financial condition and business prospects, and cause our actual results to differ materially from those projected in any forward-looking statements.

Risks Related to Our Company

We have incurred net losses, experienced net cash outflows from operating activities and recorded working capital deficits. If we do not effectively manage our cash and other liquid financial assets and execute our liquidity plan, we may not be able to satisfy repayment requirements on our borrowings.

We incurred net losses of $15.1 million, $6.3 million and $44.8 million in 2019, 2020 and 2021, respectively. We had an accumulated deficit of $637.4 million as of December 31, 2021. We also had a working capital deficit of $90.0 million as of December 31, 2021. In addition, we have substantial amounts of debt that became due in 2022. These conditions raise substantial doubt about the Company's ability to continue as a going concern.

Historically, we have financed our operations primarily through cash flows from bank borrowings, financing from issuance of convertible bonds, operating activities and proceeds from private placements and registered offerings. We expect that our existing cash and cash equivalents and cash flows from operating and financing activities will be sufficient to meet our anticipated working capital requirements and capital expenditures for at least the next 12 months. However if we failed to achieve the goal, we may need additional financing to repay debt obligation and execute our business plan, and we may not be able to obtain the necessary additional capital on a timely basis, on acceptable terms, or at all. Without access to sufficient level of capital from operations or through bank borrowings or other sources, we may not be able to execute our growth strategy or pursue additional projects, or may not even be able to satisfy repayment requirements on our borrowings. These uncertainties may create concerns for our creditors, suppliers, customers and other counterparties, and cause them to make it more difficult for us to raise our financing, conduct our business and meet our debt and other obligations.

Although we have formulated a plan as summarized under Note 2 to our consolidated financial statements appearing elsewhere in this annual report to continue implementing various measures to boost revenue and control the cost and expenses within an acceptable level, and other measures including negotiate with potential buyers for sales of Solar PV projects, obtain equity financing from certain subsidiaries’ initial public offering and seek credit facilities, we cannot assure you that we will be able to successfully execute this plan. The amount of liquidity that we need may be greater than we currently anticipate as a result of additional factors and events beyond our control, such as global economic slowdown, potential financial crises globally or in any region where we conduct a significant portion of our business, changes in the regulatory and business environments, including international trade-related sanctions, which may prevent us from operating normally or from effectively competing in the PV industry. All of these and other factors and occurrences may increase our cash requirements and make us unable to satisfy repayment requirements on our borrowings.

We have recognized the fact that additional actions were needed to reposition our operations to minimize our cash outflows. Therefore, we undertook a number of initiatives in order to conserve or generate cash on an incremental basis in 2021. For a detailed discussion of these initiatives and strategies, please see “Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations—B. Liquidity and Capital Resources— Capital Resources and Material Known Facts on Liquidity.”

However, there is no assurance that these initiatives and strategies will be successfully implemented, or even if successfully implemented, our cash position and our operational efficiency will be improved. In the event that our business initiatives and strategies do not achieve the expected results, our business, financial conditions, results of operations and liquidity position may be materially and adversely affected. Furthermore, we have identified several business related risk factors, such as compliance with laws and regulations, contingent liabilities arising from litigations, suspected related party transactions and unusual transactions, which could cause cash position to further deteriorate.

We are in default on a number of our obligations, which could result in our being forced to cease operations if we are unable to reach satisfactory settlement with applicable counterparties.

We have outstanding convertible bonds of $35.0 million under a convertible bond agreement (“Convertible Bond Agreement”) with certain bond holders, which were defaulted in June 2016 and not repaid through December 31, 2021.

If we are unable to reach satisfactory settlement with applicable counterparties, we could be forced to cease operations.

Our substantial indebtedness could adversely affect our business, financial condition and results of operations.

We require a significant amount of cash to meet our capital requirements and fund our operations, including payments to suppliers for PV modules and components and to banks for project loans. As of December 31, 2021, we had $9.1 million in outstanding short-term borrowings (and the current portion of long-term borrowings) and $12.8 million in outstanding long-term borrowings (excluding the current portion).

Our existing debt may have significant consequences on our operations, including:

Any of these factors and other consequences that may result from our substantial indebtedness could have an adverse effect on our business, financial condition and results of operations as well as our ability to meet our payment obligations under our existing debt facilities. Our ability to meet our payment obligations under our existing debt facilities depends on our ability to generate significant cash flow in the future. This, to some extent, is subject to general economic, financial, competitive, legislative and regulatory factors as well as other factors that are beyond our control.

Our management has identified material weaknesses in our internal control over financial reporting and we may not be able to remediate these weaknesses. Additionally, our management may identify material weaknesses in the future that could adversely affect investor confidence, impair the value of our securities and increase our cost of raising capital.

Our independent registered public accounting firm has conducted an audit of our internal control over financial reporting. In the course of auditing our internal control, we and our independent registered public accounting firm identified certain material weaknesses in our internal control over financial reporting, and concluded that our disclosure and internal controls and procedures were not effective as of December 31, 2021. See “Item 9A. Controls and Procedures” for more information. There can be no assurance as to how quickly or effectively we can remediate the material weaknesses in our internal control over financial reporting or that additional material weaknesses will not be identified in the future.

Any failure to remedy additional weaknesses or deficiencies in our internal control over financial reporting that may be discovered in the future or to implement new or improved controls, or difficulties encountered in the implementation of such controls, could harm our operating results, cause us to fail to meet our reporting obligations or result in material misstatements in our financial statements. Any such failure could, in turn, affect the future ability of our management to certify that our internal control over financial reporting is effective. Ineffective internal control over financial reporting could also subject us to the scrutiny of the SEC and other regulatory bodies which could cause investors to lose confidence in our reported financial information and subject us to civil or criminal penalties or shareholder litigation, which could have an adverse effect on the trading price of our securities.

In addition, if we identify additional deficiencies in our internal control over financial reporting, the disclosure of that fact, even if quickly remedied, could reduce the market’s confidence in our financial statements and harm our share price. Furthermore, additional deficiencies could result in future non-compliance with Section 404 of the Sarbanes-Oxley Act of 2002 (“Sarbanes-Oxley”). Such non-compliance could subject us to a variety of administrative sanctions, including review by the SEC or other regulatory authorities.

We rely substantially on our senior management team and our ability to attract, train and retain qualified personnel for our current and future success.

The industry experience, expertise and contributions of our chairman, Mr. Xiaofeng Peng, is essential to our continuing success. We will continue to rely on our senior management, regional management and other key employees to manage our business operations and implement our growth plans. If they cannot work together effectively or efficiently, our business may be severely disrupted. If one or more of our senior or regional management personnel were unable or unwilling to continue to hold their present positions, we might not be able to recruit, train and retain personnel with comparable qualifications, and our results of operations and financial condition may be materially and adversely affected.

Our qualified and experienced project development teams are critical to our success. We may not be able to continue to attract, train and retain qualified personnel, including executive officers, project development personnel, project management personnel and other key personnel with the necessary experience and expertise. In particular, as we enter into new markets, we face challenges to recruit and retain qualified personnel who are familiar with local regulatory regimes and have adequate experiences in project development and operations. In particular, we have experienced a lack of accounting personnel with an appropriate level of knowledge and experience in U.S. GAAP.

There is substantial competition for qualified personnel in the industries we operate. Our competitors may offer more competitive packages or otherwise attract our personnel. Our costs to retain qualified personnel may also increase in response to competition. If we fail to continue to attract and retain a sufficient number of personnel with suitable managerial, technical or marketing expertise, our business operations could be adversely affected and our future growth and expansions may be inhibited.

We have limited insurance coverage.

Our insurance policies cover employee-related accidents and injuries, property damage, machinery breakdowns, fixed assets, facilities and liability deriving from our activities, including environmental liability. We consider our current insurance coverage to be adequate, but we cannot assure you that our insurance will be sufficient or effective under all circumstances and against all hazards or liabilities to which we may be subject. Furthermore, our insurance coverage is subject to deductibles, caps, exclusions and other limitations. A loss for which we are not fully insured could have a material adverse effect on our business, financial condition, results of operations and cash flows. Furthermore, due to rising insurance costs and changes in the insurance markets, we cannot assure you that our insurance coverage will continue to be available at comparable rates or on similar terms, if at all. We may also reduce or cancel our insurance coverage at any time. We may not be able to maintain or obtain insurance of the type and amount we desire at reasonable rates and we may elect to self-insure a portion of our solar project portfolio. Any losses not covered by insurance could have a material adverse effect on our business, financial condition, results of operations and cash flows.

In addition, the insurance industry in many parts of the world is still in an early stage of development. As we continue to expand our global presence, we cannot assure you that we will be able to obtain adequate insurance coverage in each of the new markets we enter. To the extent that our operations are not adequately insured in these markets, our business, financial condition and results of operations may be materially and adversely affected.

Changes to our business strategy provide a limited history on which to base our prospects and anticipated results of operations. Our historical operating results may not serve as an adequate basis to evaluate our future prospects and results of operations.

For the past few years, we have expanded our global project development business under our independent power producer model, or IPP model, or our build-and-transfer model, or BT model, by ramping up our portfolio of solar projects. We entered into EV industry and roofing and solar system installation industry by acquiring Phoenix and certain assets of PDI in 2019 and 2020. This limited operating history may not be a reliable indicator of our future performance.

Given our limited operating history under the current business model, we may not be able to ascertain and allocate the appropriate financial and human resources necessary to grow these new business areas. We may invest considerable capital into growing these businesses but fail to address market or customer demands or otherwise fail to achieve satisfactory financial return. In particular, our results of operations, financial condition and future success depend largely on our ability to continue to identify suitable projects that complement our solar project pipeline through acquisitions and secondary development, as well as our ability to obtain the required regulatory approvals, financing and cost-effective construction services for these acquisitions. We must also sustainably manage and operate the solar projects that we acquire, develop and hold under our IPP model, or successfully identify buyers for solar projects under our BT model  . The success of our EV business depends on the development of new drive systems and new vans to attract customers, the supply of EV components and batteries as well as the government policies and incentives. For the new acquired roofing and solar system installation, we must compete and obtain contracts from customers, and have the ability the install and connect the roof solar. In addition, in expanding into these new business areas, we may be competing against companies that have substantially more experience than we do. If we are unable to achieve growth in these new business areas, our overall growth and financial performance may be inferior to our competitors and our operating results could be adversely impacted.

Period-to-period comparisons of our operating results and our results of operations for any period should not be relied upon as an indication of our performance for any future period. We have incurred net losses since our inception, and, as of December 31, 2021, we had an accumulated deficit of approximately $637.4  million. We may not be able to achieve or maintain profitability in the near future.

We conduct our business in diverse locations around the world and are subject to economic, regulatory, social and political risks internationally and in the regions where we operate.

We currently conduct our business operations in the U.S., Japan, U.K., Greece, Italy, Australia and Canada, and as of March 30, 2022, we own and operate 16.8 MW of solar projects and have 19.95 MW of solar projects under construction across the world. Our business is therefore subject to diverse and constantly changing economic, regulatory, social and political conditions in these markets.

 Operating internationally exposes us to a number of risks globally and in each of the markets where we operate, including, without limitation:

If economic recovery is slow in the markets where we operate, our business, financial condition, results of operations and prospects could be materially and adversely affected. Moreover, as we expand into additional markets, we may face unfamiliar regulatory regimes, business practices, governmental policies and industry conditions. As a result, our experience and knowledge of our existing markets may not be applicable to new markets that we enter, requiring significant time and resources to adapt our business to these unfamiliar markets. To the extent that our diverse business operations are affected by unexpected and adverse economic, regulatory, social and political conditions, we may experience business disruptions, loss of assets and personnel and other indirect losses and our business, financial condition and results of operations both locally and internationally could be materially and adversely affected.

Risks Related to Our Solar Projects Business

The reduction, modification, delay or discontinuation of government subsidies and other economic incentives for the solar industry may reduce the profitability or viability of our solar projects and materially adversely affect our business.

At present, solar power is not cost competitive with other energy sources in our existing markets and the new markets we plan to expand into. For a variety of technological and economic reasons, the cost of generating electricity from solar energy in these markets currently exceeds and, absent significant changes in technological or economic circumstances, will continue to exceed the cost of generating electricity from conventional and certain other competing energy sources. Therefore, government subsidies and incentives, primarily in the form of feed-in tariffs, or FIT, price support schemes, tax credits, net metering and other incentives to end users, distributors, system integrators and manufacturers of solar products are generally required to enable companies such as us to successfully operate in these markets.

Government subsidies and incentives vary by geographic market. The availability and size of such subsidies and incentives depend, to a large extent, on political and policy developments relating to environmental concerns and other macro-economic factors. These government subsidies and incentives are expected to gradually decrease in scope or be discontinued as solar power technology improves and becomes more affordable relative to other types of energy. Reductions have occurred in certain countries where we have operations, and subsidies and incentives may be further reduced or discontinued in countries where we currently or intend to operate. Reductions may apply retroactively to existing solar projects, which could significantly reduce the value of our existing solar projects and other businesses. Even if reductions in government subsidies and economic incentives apply only to future solar projects, our operations in that country could be materially and adversely affected as we would not be able to leverage our existing presence to drive further growth. Moreover, certain solar subsidies and incentives are designed to expire or decline over time, are limited in total funding, require renewal from regulatory authorities or impose certain investment or performance criteria on our business partners or us, which we may not be able to satisfy. In addition, we may not be able to upgrade our technologies rapidly enough to compensate for foreseeable reductions in government subsidies and incentives. As a result, a significant reduction in the scope or discontinuation of government incentive programs in our existing and target markets could have a material adverse effect on our business, financial condition, results of operations and prospects.

The significant period of time between our upfront investments in solar projects and their commencement of revenue generation could materially and adversely affect our liquidity, business and results of operations.

There is a significant gap between the time that we make significant upfront investments in the solar projects and the time that we receive any revenue from the electricity generated by these solar projects after grid connection (under our IPP model) or from the sale of these projects (under our BT model). These upfront investments include, among others, legal, accounting and other professional fees, costs associated with feasibility studies and due diligence, payments for land use rights, construction costs, government permits and deposits for grid connection agreements and PPAs, none of which may be refundable if a project fails to achieve completion. We have historically relied on private placements, bank loans and financial leases to cover costs and expenses incurred during project development.

In particular, there could be an especially long gap between the initial assessment of a project, the first steps of acquiring land use rights and negotiating interconnection agreements and the obtaining of governmental approvals for construction. Acquisition of land use rights can be particularly time-consuming if we are engaged in primary development and need to negotiate with land owners or government entities. The significant development time increases the risk for adverse events during such process, whether they be economic, environmental, political, social or otherwise, that could cause further delays in project development or increase the overall development costs. Due to such adverse developments or unanticipated delays, we may be unable to recoup our initial investment in the solar projects, which may materially and adversely affect our liquidity, profitability and results of operations.

In addition, we will need to hire and train additional project development personnel to manage our growing portfolio of IPP and BT projects. If we are unable to manage our growth effectively, we may not be able to take advantage of market opportunities, execute our business strategies successfully or respond to competitive pressures. As a result, our business, prospects, financial condition and results of operations could be materially and adversely affected.

The market for solar project development is highly competitive.

There is currently intense competition in the solar industry, particularly in the downstream project development segment. Solar projects encounter competition from utilities, industrial companies and other independent power producers. In recent years, there has been increasing competition for the award of PPAs, which has in some markets resulted in an excess supply above designated reserve margins and has been contributing to the declining electricity prices in many markets. In light of these conditions, we may not be able to obtain PPAs for our new solar projects under our IPP model, and we may not be able to renew PPAs on the same terms and conditions upon expiration, particularly in terms of securing an electricity sale price that enables profitable operation or the sale of a project at anticipated value, if at all.

We have expanded our business to include global project development and may not have the same level of expertise and customer base as our competitors, which may affect our ability to successfully establish our presence in the global market. Our current or potential competitors may have greater operational, financial, technical, market share, scale, management or other resources than us in our existing or target markets. Our competitors may also enter into strategic alliances with other competitors to our detriment, or may ally with our suppliers or contractors, thereby limiting our procurement choices and our flexibility in project development. Our current or potential competitors may offer PV solutions comparable or superior to ours at the same or lower prices, or adapt more quickly to industry trends than we do. Increased competition may result in price reductions, reduced profit margins and loss of market share.

We may not be able to obtain long-term contracts for the sale of electricity generated by our solar projects under our IPP model at prices and on other terms favorable to attract financing and other investments.

Obtaining long-term contracts for the sale of electricity generated by our solar projects under our IPP model at prices and on other terms favorable to us will be essential for obtaining financing or completing construction of these projects. We must compete for PPAs against other developers of solar and renewable energy projects. Furthermore, other sources of power, such as natural gas-fired power plants, have historically been cheaper than the cost of solar power and power from certain types of projects, such as natural gas-fired power plants, can be delivered on a firm basis. The availability of PPAs is subject to a number of economic, regulatory, tax and public policy factors. The inability to compete successfully against other power producers or otherwise enter into PPAs favorable to us would negatively affect our ability to develop and finance our projects and negatively impact our revenue.

Our solar projects have short operating histories and may not perform up to our expectations.

The projects in our solar project portfolio are relatively new with expected operating life of more than 20 years. The majority of our projects in operation as of December 31, 2021 commenced operations since 2014. In addition, the projects we acquire in the future may not have commenced construction or operation or otherwise have a limited operating history. As a result, our assumptions and estimates regarding the future performance of these projects are, and will be, made without the benefit of a meaningful operating history, which may impair our ability to accurately assess the potential profitability of the projects. The performance of these projects will also be subject to risks inherent in newly constructed renewable energy projects, including breakdowns and outages, latent defects, equipment that performs below our expectations and system failures. Failure of some or all of our projects to perform up to our expectations could have a material adverse effect on our business, financial condition and results of operations.

Our results of operations may be subject to fluctuations.

Before we achieve economies of scale in terms of our IPP projects and receive steady electricity generation income, our revenue in a given period will depend on the number of solar projects sold under our BT model and sale of PV modules and solar component, and therefore is subject to significant fluctuations. For instance, we may generate a significant portion of our revenues from the one-time sale of solar projects for certain periods. Moreover, certain aspects of our operations will also be subject to seasonal variations. For example, we may schedule significant construction activities to connect solar projects to the grids prior to a scheduled decrease in FIT rates in order to qualify for more favorable FIT policies.

We act as the general contractor for our customers for the provision of EPC services, and are subject to risks associated with construction, delays and other contingencies, which could have a material adverse effect on our reputation, business and results of operations.

Historically, we have generated a significant portion of our revenue from the provision of EPC services. We generally enter into fixed-price EPC contracts under which we act as the general contractor for our customers in connection with the installation of their solar power systems. All essential costs are estimated at the time of entering into the EPC contracts for a particular project, and are reflected in the overall fixed-price that we charge our customers. These cost estimates are preliminary and may or may not be covered by contracts between us or our subcontractors, suppliers or other parties to the project. In addition, we engage qualified and licensed subcontractors for the construction of our EPC projects. Shortages of such skilled labor could significantly delay a project or otherwise increase our costs. Should miscalculations in project planning or delay in execution occur (including those due to unexpected increases in inflation, commodity prices or labor costs), we may not be able to achieve our expected margins or recover our costs.

In addition, our EPC contracts generally provide for performance milestones. Delays in supply of PV module or components, construction delays, unexpected performance problems in electricity generation or other events may cause us to fail to meet these performance criteria, resulting in unanticipated and severe revenue and earnings losses and financial penalties. If we are unable to complete the development of a solar project, or fail to meet one or more agreed target construction milestone dates, any agreed upon system-level capacity or energy output guarantees or warranties (including, for some projects, twenty-five year performance warranties) or other terms under our EPC contracts, or the solar projects we develop cause grid interference or other damage, we may be subject to termination of such contracts or significant damages, penalties and/or other obligation under the EPC agreements or other agreements relating to the projects (including obligations to repair, replace and/or supplement additional modules and balance of system materials for the projects), particularly if our liabilities are not capped under the terms of such agreements, and we may not be able to recover our investment in the project. The occurrence of any of these events could have a material adverse effect on our reputation, business and results of operations.

We generally recognize revenue from EPC services on a “cost-based input method” and payments are due upon the achievement of contractual milestones and any delay or cancellation of a project could adversely affect our business.

We generally recognize revenue from our EPC services on a “cost-based input method,” and as a result, revenues from our EPC services are driven by the performance of our contractual obligations, which is in turn generally driven by timelines of the installation of solar power systems at customer sites. Such arrangement could result in unpredictability of revenue and in the near term, a revenue decrease. As with any project-related business, there is potential for delays within any particular customer project. Variation of project timelines and estimates may impact our ability to recognize revenue in a particular period. In addition, certain EPC contracts may provide for payment milestones due at specified stages throughout the development of a project. Because we must invest substantially in a project in advance of achieving these milestones and receiving payments, delay or cancellation of a project could adversely affect our business and results of operations.

We may be subject to product or strict liability claims if the provision of our EPC services or the solar projects we sell result in injury or damage, and we have limited insurance coverage to protect against such claims, as well as losses that may result from business interruptions or natural disasters.

Solar projects are highly sophisticated and generate and transfer large volumes of electric charge with the potential to harm or kill, whether by improper installation or other causes. We are therefore exposed to an inherent risk of product liability claims or class action suits in the event that the installation of the solar power systems during the provision of our EPC services, or the solar projects we sell under our BT model, results in injury or damage, and we may even be liable in some jurisdictions under a strict liability theory, where liability holds even if we are not negligent or at fault. Moreover, to the extent that a claim is brought against us, we may not have adequate resources to defend ourselves. We rely on our general liability insurance to cover product liability and other liability claims and have not separately obtained product liability insurance. The unfavorable settlement of product or strict liability claims against us could result in significant monetary damages and significant payments in excess of our insurance coverage could have a materially adverse effect on our financial results. Any such business disruption could result in substantial costs and diversion of resources.

We may be subject to unforeseen costs, liabilities or obligations when providing O&M services.

We provide ongoing O&M services to third-party solar projects under fixed-price long-term service agreements, pursuant to which we generally perform all scheduled and unscheduled maintenance and operating and other asset management services for the system. Our costs to perform these services are estimated at the time of entering into the O&M agreement for a particular project, and these are reflected in the fixed-price that we charge our customers under the O&M agreement. Should miscalculations in estimating these costs occur (including those due to unexpected increases in inflation or labor costs), our O&M services may not be profitable and our growth strategy and results of operations could be adversely affected. Because of the long-term nature of these O&M agreements, the adverse impacts on results of operations could be significant, particularly if our liabilities are not capped or subject to an above- market liability cap under the terms of the O&M agreement. In addition, we may be subject to substantial costs, liabilities or obligations in the event that the solar projects we maintain and operate do not meet any agreed-upon system-level availability or performance warranties.

Warranties provided by our suppliers and contractors may be limited or insufficient to compensate for our losses, or may not cover the nature of our losses incurred.

We expect to benefit from various warranties, including product quality and performance warranties, provided by our suppliers and contractors. These suppliers and contractors, however, may file for bankruptcy, cease operations or otherwise become unable or unwilling to fulfill their warranty obligations. Even if a supplier fulfills its warranty obligations, the warranty may not be sufficient to compensate us for all of our losses. In addition, the warranty for inverters and transformers generally expire after 5 to 10 years from the date such equipment is delivered or commissioned and is subject to liability limits. Where damages are caused by defective products provided by our suppliers or construction services delivered by our contractors, our suppliers or contractors may be unable or unwilling to perform their warranty obligations as a result of their financial conditions or otherwise. Or if the warranty has expired or a liability limit has been reached, there may be a reduction or loss of warranty protection for the affected projects, which could have a material adverse effect on our business, financial condition and results of operations.

Solar energy generation depends heavily on suitable meteorological conditions. If weather conditions are unfavorable, our power generation output, and therefore the revenue from our solar projects, may be substantially below our expectations.

The electricity produced and revenues generated by solar projects are highly dependent on suitable solar conditions and associated weather conditions. Such conditions are beyond our control. Furthermore, components of these generation systems, including solar panels and inverters, can be damaged by severe weather, such as heavy snowstorms, hailstorms, ice storms, lightning strikes, extreme winds, earthquakes or tornadoes. Replacement and spare parts for key components may be difficult costly or unavailable. Unfavorable weather and atmospheric conditions could reduce the electricity output of our solar projects to below projected generation, damage or impair the effectiveness of our projects or require shutdown of key equipment, impeding operation of our projects and our ability to achieve forecasted revenues and cash flows.

The amount of electricity solar projects produce is dependent in part on the amount of sunlight, or insolation, where the projects are located. Because shorter daylight hours in winter months results in less insolation, the generation of particular projects will vary depending on the season.

We base our investment decisions with respect to solar power generation assets on the findings of related solar studies conducted prior to construction or based on historical conditions at existing projects. However, actual climatic conditions at an asset site may not conform to the findings of these studies. For example, unexpected development of climate conditions that was not taken into consideration during the investment decision-making process, such as smog and sand storms may significantly reduce the solar power generation. Therefore, our solar projects may not meet anticipated production levels or the rated capacity of our projects, which could adversely affect our business, financial condition, results of operations and cash flows.

The operation of solar projects involves significant inherent risks and hazards that could have a material adverse effect on our business, financial condition, results of operations and cash flows.

The operation of solar projects involves numerous hazardous activities, including delivering electricity to transmission and distribution systems. We are subject to natural disasters such as earthquakes, floods, snow obscuration, high temperatures, lightning, hurricanes, long-term climate changes, volcanoes and wind risks, as well as other inherent risks affecting resource availability such as fire, explosion, soil and ice buildup, structural collapse and equipment failure. Moreover, we may suffer from negligent acts by our PPA counterparties or other third parties. Our rooftop projects could cause damage to the building roof, resulting in claims due to water damages or replacement of roofing materials. These and other hazards can cause significant personal injury or loss of life, severe damage to, and destruction of, property and equipment and contamination of, or damage to, the environment, wildlife takes or fatalities and suspension of operations. The occurrence of any of these events may result in lawsuits against us asserting claims for substantial damages, including for environmental cleanup costs, personal injury and property damage and fines and/or penalties.

In addition, the ongoing operation of solar projects face risks that include the breakdown or failure of equipment or processes or performance below expected levels of output or efficiency due to wear and tear, latent defect, design error or operator error or force majeure events, among others. Unplanned outages, including extensions of scheduled outages, occur from time to time and are an inherent risk of our business. Unplanned outages typically increase our operation and maintenance expenses and may reduce our revenues as a result of generating and selling less electricity.

If we fail to properly operate and maintain our solar projects, these projects may experience decreased performance, shortened operating life or shut downs. Our solar projects may also require periodic upgrading and improvement. Changes in our own operation or local conditions may increase the costs of operating the project, including costs related to labor, equipment, insurance and taxes. If we cause damage to third parties, we may become liable for the consequences of any resulting damage. We may also experience equipment malfunction or failure, leading to unexpected maintenance needs, unplanned outages or other operational issues. In addition, inconsistencies in the quality of solar panels, PV modules, balance-of-system components or maintenance services for our solar projects may affect the system efficiency of our projects.

Any unexpected operational or mechanical failure, including failure associated with breakdowns and forced outages, and any decreased operational or management performance, could reduce our solar projects’ power generating capacity below expected levels, reducing our revenues and profitability. Degradation of the performance of our solar projects above levels provided for in the relevant PPAs may also reduce our revenues. Unanticipated capital expenditures associated with maintaining, upgrading or repairing our projects may also reduce our profitability. In addition, damage to our reputation due to system failure or accidents could negatively impact our relationships with customers and local government authorities, which could also materially adversely affect our business. Negative public or community response to solar energy projects could adversely affect the approval for and construction of our projects. We maintain insurance coverage that we consider adequate but we cannot assure you that our insurance will be sufficient or effective under all circumstances and against all hazards or liabilities to which we may be subject.

We may encounter unexpected difficulties when developing solar power projects.

The development of solar projects involves numerous risks and uncertainties and require extensive research, planning and due diligence. Before we can determine whether a solar project is economically, technologically or otherwise feasible, we may be required to incur significant capital expenditure for land and interconnection rights, preliminary engineering, permitting, legal and other work. Success in developing a particular solar project is contingent upon, among others:

Successful completion of a particular solar project may be adversely affected by numerous factors, including, without limitation:

Accordingly, some of the solar projects in our portfolio may not eventually commence operation and connect to the grid, or even proceed to construction. If a number of our solar projects are not completed, our business, financial condition and results of operations could be materially and adversely affected.

We rely on third-party suppliers and contractors when developing our solar power projects.

We source PV modules and other balance-of-system components from a wide selection of third-party suppliers and engage third-party contractors for the construction of solar projects. We typically enter into contracts with our suppliers and contractors on a project-by-project basis and do not maintain long-term contracts with our suppliers or contractors. Therefore, we are generally exposed to price fluctuations and availability of PV modules and balance-of-system components sourced from our suppliers and construction services procured from our contractors. For example, in light of changing market dynamics and government policies, the price and availability of PV modules have been subject to significant volatility in recent years. Increases in the prices of PV modules or balance- of-system components, decreases in their availability, fluctuations in construction, labor and installation costs, or changes in the terms of our relationship with our suppliers and contractors may increase the cost of procuring equipment and engaging contractors and hence materially adversely affect our financial condition and results of operations.

Furthermore, the delivery of defective products or products or construction services by our suppliers or contractors which are otherwise not in compliance with contract specifications, or the late supply of products or construction services, may cause construction delays or solar power projects that fail to adhere to our quality and safety standards, which could have a material adverse effect on our business, results of operations, financial condition and cash flow.

Our construction activities may be subject to cost overruns or delays.

We engage third-party contractors for the construction of solar projects. Construction of solar projects involves numerous risks and uncertainties, and may be adversely affected by circumstances outside of our control, including seasonal changes, inclement weather, failure to receive regulatory approvals on schedule or third-party delays in supplying PV modules or other materials. We may not be able to negotiate satisfactory construction agreements with third-party contractors, or our third-party contractors may not be able to contract with their subcontractors on a timely basis. In addition, if our contractors fail to adhere to our quality standards or otherwise fail to meet their contractual obligations, or if there is a shortage of contractors or labor strikes that prevents our contractors from completing their construction work on schedule or within budget, the solar projects may experience significant delays or cost overruns. Increases in the prices of solar products and components may also increase our procurement costs. Labor shortages, work stoppages and labor disputes could significantly delay a project or otherwise increase our costs. In addition, delays in obtaining or failure to obtain required construction permits could also delay or hinder the construction of our solar projects. A lack of proper construction permits, or post-construction approvals could delay or prevent our solar projects from commencing operation and connecting to the grid.

We may not be able to recover any of our losses resulting from construction cost overruns or delays. In addition, since the FIT applicable to a solar project generally depends on its lead time to grid connection, construction and connection delays may lead to a lower-than-expected FIT, which would adversely affect the long-term value and potentially the viability of the project. Many PPAs also require our solar projects to connect to the grid by a certain date. If the construction of solar project is significantly delayed, we may be in violation of our PPAs or may only be entitled to reduced FIT payments, if at all. A reduction or forfeiture of FIT payments would materially and adversely affect the profitability for a solar power project. Any of the above contingencies could lead to our failure to generate expected return from our solar projects and result in unanticipated and significant revenue and earnings losses.

The solar industry faces competition from both conventional power industries and other renewable power industries.

The solar industry faces intense competition from all other players within the energy industry, including both conventional energy providers such as nuclear, natural gas and fossil fuels and other renewable energy providers, such as geothermal, hydropower, biomass, wind and nuclear energy. Other energy sources may benefit from innovations that reduce their costs and increase safety, and therefore improve their competitiveness. New natural resources may be discovered, or global economic, business or political developments may disproportionately benefit conventional energy sources or other renewable energy sources at the expense of solar. Governments may strengthen their support for other renewable energy sources and reduce their support for the solar industry. Changes in supply and demand of conventional energy sources or other energy sources may reduce the cost of such sources and render solar power less attractive. The decline in oil prices would adversely impacted the competitiveness of solar energy. Failure for our customers, other business partners or us to compete with the providers of other energy sources may materially and adversely affect our business, results of operations and financial condition.

We may not be able to acquire additional solar projects to grow our project portfolio or effectively integrate or realize the anticipated benefits of our acquisitions.

Our current business strategy includes plans to further increase the number of solar projects we own and operate. We have significantly expanded our operations through acquisitions of solar projects across different development stages in Japan, the U.S., the U.K., Greece and Italy, and we may acquire additional businesses, products or technologies or enter into joint ventures or other strategic initiatives in the future. Accordingly, our ability to execute our expansion strategies depends on our ability to identify suitable investment or acquisition opportunities, which is subject to numerous uncertainties. We may not be able to identify favorable geographical markets for expansion or assess local demand for solar power, identify a sufficient number of projects as contemplated, or secure project financing and refinancing on reasonable terms for the contemplated acquisitions. In addition, our competitors may have substantially greater capital and other resources than we do, and may be able to pay more for the acquisition targets we identify and may be able to identify, evaluate, bid for and acquire a greater number of projects than our resources permit.

Furthermore, we may not realize the anticipated benefits of our acquisitions and each transaction involves numerous risks, including, among others:

Acquisitions of companies are inherently risky, and ultimately, if we do not generate expected economic returns from the acquired businesses, or become responsible for any preexisting liabilities related to the acquired businesses, we may not fully realize the anticipated benefits of the acquisitions, which could adversely affect our business, financial condition or results of operations.

We may fail to comply with laws and regulations in the markets we operate.

The development, construction and operation of solar projects are highly regulated. We conduct our operations in many jurisdictions and are subject to different laws and regulations, including national and local regulations relating to building codes, taxes, safety, environmental protection, utility interconnection, metering and other matters. Our establish subsidiaries also have operations in these countries and jurisdictions that are required to comply with various local laws and regulations. While we strive to work with our local counsel and other advisers to comply with the laws and regulations of each jurisdiction where we operate, there have been, and may continue to be, instances of non-compliances such as late filings of annual accounts with the appropriate governmental authorities, failure to notify governmental authorities of certain transactions, failure to hold annual meetings as required, failure to register director or address changes or other local requirements which may result in fines, sanctions or other penalties against our non-complying subsidiaries and its directors and officers. While we do not believe our past and continuing non-compliances, singularly or in the aggregate, will have a material adverse effect on our business, financial condition or results of operations, we cannot assure you that similar or other non-compliances will not occur in the future which may materially and adversely affect our business, financial condition or results of operations.

We are responsible for obtaining a variety of approvals, permits and licenses from various authorities for our solar projects. The procedures for obtaining such approvals, permits and licenses vary from country to country, making it onerous and costly to adhere to the varying requirements and standards of individual localities. Failure to obtain the required approvals, permits or licenses or to comply with the conditions associated therewith may result in fines, sanctions, suspension, revocation or non-renewal of approvals, permits or licenses, or even criminal liabilities, which could material and adversely affect our business, financial condition and results of operations. In addition, new government regulations pertaining to our business or solar projects may result in significant additional expenses. We cannot assure you that we will be able to promptly and adequately respond to changes of laws and regulations in various jurisdictions, or that our employees and contractors will act in accordance with our internal policies and procedures. Failure to comply with laws and regulations where we develop, own and operate solar projects may materially and adversely affect our business, results of operations and financial condition. The market demand for solar power is strongly influenced by government regulations and policies concerning the electric utility industry as well as by policies promulgated by electric utilities in each of the markets we operate. These regulations and policies often relate to electricity pricing and technical interconnection of electricity generation. Customer purchases of alternative energy sources, including solar power technology, could be deterred by these regulations and policies, which may significantly reduce the demand for our PV solutions. For example, without a regulatory-mandated exception for solar power systems, utility customers are often charged interconnection or standby fees for putting distributed power generation on the electric utility grid or limit the production capacity to the grid. The county-level government may also levy additional tax related to land use or potential plants recovery that was not initially included during the development or construction phase. These fees could increase, rendering solar power less cost competitive in these markets and our PV solutions less desirable.

It is difficult to ensure ongoing compliance with the changing requirements of individual markets. Any new government regulations or utility policies pertaining to solar projects may result in significant additional expenses to us or other industry participants and as a result could cause a significant reduction in demand for our PV solutions.

Environmental, health and safety laws and regulations subject us to extensive and increasingly stringent operational requirements, as well as potentially substantial liabilities arising out of environmental contamination.

We are subject to, in each of the jurisdictions we operate, numerous national and local laws, regulations, guidelines, policies, directives and other requirements governing or relating to, among others, land use and zoning matters and protection of human health and the environment, including those limiting the discharge and release of pollutants into the environment, and the protection of certain wildlife. These laws and regulations require our solar projects to, among others, obtain and maintain approvals and permits, undergo environmental impact assessments and review processes and implement environmental, health and safety programs and procedures to control risks associated with the construction, operation and decommissioning of solar projects. If our solar projects do not comply with applicable environmental laws, regulations or permit requirements, we may be required to pay significant fines or penalties or suspend or cease operations of the affected projects. Violations of environmental and other laws, regulations and permit requirements may also result in criminal sanctions or injunctions.

Our solar projects may experience malfunctions and other unplanned events that result in personal injury and property damage. As such, the operation of our projects carries an inherent risk of environmental, health and safety liabilities (including potential civil actions, compliance or remediation orders, fines and other penalties), and may subject us to administrative and judicial proceedings. In addition, certain environmental laws and regulations may impose joint and several liability on past and present owners and operators of sites, related to the cleaning up of sites where hazardous wastes or materials were disposed or released.

Technological advances in the solar industry could render our PV solutions uncompetitive or obsolete.

The solar industry is characterized by its rapid adoption and application of technological advances. This requires us to develop new PV solutions and enhance our existing PV solutions to keep pace with and respond effectively to evolving technologies, market conditions and customer demands. Our competitors may develop technologies more advanced and cost-effective than ours. We will need to invest substantially in research and development to maintain our market position and effectively compete in the future. Our failure to further refine or enhance our technologies could render our technologies uncompetitive or obsolete, which could reduce our market share and cause our revenues to decline.

In addition, we may invest in and implement newly-developed, less-proven technologies in our project development or in maintaining or enhancing our existing projects. There is no guarantee that these new technologies will perform or generate customer demand as anticipated. The failure of our new technologies to perform as anticipated may materially and adversely affect our business and results of operations.

If demand for solar projects develops more slowly than we anticipate, develops in ways inconsistent with our strategy, or fails to develop at all, our business, financial condition, results of operations and prospects could be materially and adversely affected.

The solar power market worldwide is at a relatively early stage of development compared to conventional power markets and other renewable power markets, such as that for hydropower. Thus, trends in the solar industry are based only on limited data and may be unreliable. Many factors may affect the demand for solar projects worldwide, including:

Our analysis and predictions concerning the future growth of the solar industry are based on complex facts and circumstances and may be incorrect. If market demand for solar projects in our existing or target markets fails to develop according to our expectations, our business, financial condition, results of operations and prospects could be materially and adversely affected.

Our growth prospects and future profitability and our ability to continue to acquire solar projects depends on the availability of sufficient financing on terms acceptable to us.

The development of solar projects requires significant upfront cash investments, including the costs of permit development, construction and associated operations. Since 2014, we have been expanding our solar project portfolio primarily by acquiring solar projects across different development stages. Such expansion strategy requires significant upfront capital expenditures which, depending on the respective development stages of the acquired projects, may not be recouped for a significant period of time. As a result, we are required to pursue a wide variety of capital resources to fund our operations, including private placements, bank loans, financial leases and other third-party financing options.

Our ability to obtain sufficient financing is subject to a number of uncertainties, including:

Due to these or other reasons, we may not be successful in obtaining the required funds for future acquisitions. Furthermore, we may be unable to refinance our bank borrowings on favorable terms, or at all, upon the expiration or termination of our existing loan facilities. In addition, rising interest rates could adversely affect our ability to secure financing on favorable terms. Our failure in securing suitable financing sources in a timely manner or at all, or on commercially acceptable terms, could significantly limit our ability to execute our growth strategies or future acquisitions, and may have a material adverse effect on our business, financial condition, results of operations and cash flows.

Risks Related to Our PV Components Business

Debt and Collections Risks:

We may have to secure payments for certain consumer solar or battery sales but there is no assurance that such payments will be timely collected. We have also enhanced our collection efforts and undertaken various measures to collect outstanding payments from customers and may suffer damages as a result of legal actions and other payments due to us.

We currently conduct our business operations in Australia. We are in approximately 9 locations in Australia including offices/warehouse and storage facilities. Our business is therefore subject to diverse and constantly changing economic, regulatory, social and political conditions in these areas including the following:

Our sales may be subject to risks associated with construction, delays and other contingencies, which could have a material adverse effect on our reputation, business and the results of operations.

Historically, we have generated a significant portion of our revenue from sales of PV products. We generally enter into a sales contract under which we act as the supplier in connection with the supply of solar and battery systems. In addition, delays in supply of PV module or components, construction delays, pandemic delays, labor, unexpected performance problems in electricity generation or other events may cause us unanticipated and severe revenue and earnings losses and financial penalties.

 We rely on suppliers when selling our solar and battery products and may see delays and/or cancellations.

We source PV modules and other balance-of-system components from a wide selection of third-party suppliers. Therefore, we are generally exposed to price fluctuations and availability of PV modules and balance-of-system components sourced from our suppliers. For example, in light of changing market dynamics and government policies, the price and availability of PV modules and other solar materials have been subject to significant volatility in recent years. Increases in the prices of PV modules or balance-of-system components, decreases in their availability, fluctuations in construction, labor and installation costs, or changes in the terms of our relationship with our third party installers and suppliers may increase the cost of procuring equipment and hence materially adversely affect our financial condition and results of operations.

Warranties provided by our third party installers and contractors may be limited or insufficient to compensate for our losses, or may not cover the nature of our losses incurred.

We expect to benefit from various warranties, including product quality and performance warranties, provided by our installers and contractors. These suppliers and contractors, however, may file for bankruptcy, cease operations or otherwise become unable or unwilling to fulfill their warranty obligations. Even if a supplier fulfills its warranty obligations, the warranty may not be sufficient to compensate us for all of our losses. In addition, the warranty for inverters and transformers may expire after such equipment is delivered or commissioned and/or is subject to liability limits. Where damages are caused by defective products provided by our suppliers or construction services delivered by our contractors, our suppliers or contractors may be unable or unwilling to perform their warranty obligations as a result of their financial conditions or otherwise. Or if the warranty has expired or a liability limit has been reached, there may be a reduction or loss of warranty protection for the affected projects, which could have a material adverse effect on our business, financial condition and results of operations.

We may be subject to product or strict liability claims if the provision of our services or the solar projects we sell result in injury or damage, and we have limited insurance coverage to protect against such claims, as well as losses that may result from business interruptions or natural disasters.

Solar projects are highly sophisticated and generate and transfer large volumes of electric charge with the potential to harm or kill, whether by improper installation or other causes. We are therefore exposed to an inherent risk of product liability claims or class action suits in the event that the installation of the solar power systems during the provision of our services, or the solar projects we sell under our business model, results in injury or damage, and we may even be liable in some jurisdictions under a strict liability theory, where liability holds even if we are not negligent or at fault. Moreover, to the extent that a claim is brought against us, we may not have adequate resources to defend ourselves. We rely on our general liability insurance to cover product liability and other liability claims and have not separately obtained product liability insurance. The unfavorable settlement of product or strict liability claims against us could result in significant monetary damages and significant payments in excess of our insurance coverage could have a materially adverse effect on our financial results. Any such business disruption could result in substantial costs and diversion of resources.

Risks Related to Our Residential Roofing and Solar Installation Business

The solar energy industry is an emerging market which is constantly evolving and may not develop to the size or at the rate we expect.

The solar energy industry is an emerging and constantly evolving market opportunity. We believe the solar energy industry will still take several years to fully develop and mature, and we cannot be certain that the market will grow to the size or at the rate we expect. Any future growth of the solar energy market and the success of our solar service offerings depend on many factors beyond our control, including recognition and acceptance of the solar service market by consumers, the pricing of alternative sources of energy, a favorable regulatory environment, the continuation of expected tax benefits and other incentives, and our ability to provide our solar service offerings cost-effectively. If the markets for solar energy do not develop to the size or at the rate we expect, our business may be adversely affected.

Solar energy has yet to achieve broad market acceptance and depends in part on continued support in the form of rebates, tax credits, and other incentives from federal, state and local governments. If this support diminishes materially, our ability to obtain external financing on acceptable terms, or at all, could be materially adversely affected. These types of funding limitations could lead to inadequate financing support for the anticipated growth in our business. Furthermore, growth in residential solar energy depends in part on macroeconomic conditions, retail prices of electricity and customer preferences, each of which can change quickly. Declining macroeconomic conditions, including in the job markets and residential real estate markets, could contribute to instability and uncertainty among customers and impact their financial wherewithal, credit scores or interest in entering into long-term contracts, even if such contracts would generate immediate and long-term savings.

Furthermore, market prices of retail electricity generated by utilities or other energy sources could decline for a variety of reasons, as discussed further below. Any such declines in macroeconomic conditions, changes in retail prices of electricity or changes in customer preferences would adversely impact our business.

We have historically benefited from declining costs in our industry, and our business and financial results may be harmed not only as a result of any increases in costs associated with our solar service offerings, but, also, by any failure of these costs to continue to decline as we currently expect. If we do not reduce our cost structure in the future, our ability to continue to be profitable may be.

Declining costs related to raw materials, manufacturing and the sale and installation of our solar service offerings have been a key driver in the pricing of our solar service offerings and, more broadly, customer adoption of solar energy. While, historically, the prices of solar panels and raw materials have declined, the cost of solar panels and raw materials could increase in the future, and such products’ availability could decrease, due to a variety of factors, including restrictions stemming from the COVID-19 pandemic, tariffs and trade barriers, export regulations, regulatory or contractual limitations, industry market requirements, and changes in technology and industry standards.

For example, the Company has historically purchased a portion of the solar panels used in our solar service offerings from overseas manufacturers. In January 2018, in response to a petition filed under Section 201 of the Trade Act of 1974, Former President Trump imposed four-year tariffs on imported solar modules and imported solar cells not assembled into other products (the “Section 201 Module Tariffs”) that apply to all imports above a 2.5 gigawatts (GW) annual threshold. The Section 201 Module Tariffs were 30% in 2018 and stepped down by 5% annually in the second, third and fourth years. In October 2020, a proclamation was issued to increase the tariff from 15% to 18% for 2021, the final year under the original Sec. 201 proclamation imposing the tariffs. Additionally, the U.S. Trade Representative (USTR) was authorized to file a petition to extend the Sec. 201 tariffs, a decision on which could be made in the coming months.

The United States and China each imposed additional new tariffs in 2018 on various products imported from the other country. These include an additional 25% tariff on solar panels and cells that are manufactured in China and a tariff on inverters, certain batteries and other electrical equipment initially set at 10%. In May 2019, the 10% tariff was increased to 25%, and the Trump administration threatened additional incremental increases. The United States also has, from time to time, announced potential tariffs on goods imported from other countries. We cannot predict what actions may ultimately be taken with respect to tariffs or trade relations between the United States and other countries, what products may be subject to such actions, or what actions may be taken by the other countries in retaliation. The tariffs described above, the adoption and expansion of trade restrictions, the occurrence of a trade war, or other governmental action related to tariffs, trade agreements or related policies have the potential to adversely impact our supply chain and access to equipment, our costs and ability to economically serve certain markets. Any such cost increases or decreases in availability could slow our growth and cause our financial results and operational metrics to suffer. We cannot predict whether and to what extent U.S. trade policies will change under the Biden administration and cannot ensure that additional tariffs or other restrictive measures will not continue or increase.

Other factors may also impact costs, such as our choice to make significant investments to drive growth in the future.

We face competition from traditional energy companies as well as solar and other renewable energy companies.

The solar energy industry is highly competitive and continually evolving, as participants strive to distinguish themselves within their markets and compete with large utilities. We believe that our competitors include utilities that supply energy to homeowners by traditional means. We compete with these utilities primarily based on price, predictability of price, and the ease by which homeowners can switch to electricity generated by our solar service offerings. If we cannot offer compelling value to customers based on these factors, then our business and revenue will not grow. We also compete with traditional installers who face similar challenges.

The production of solar energy depends heavily on suitable meteorological and environmental conditions. If meteorological or environmental conditions are unexpectedly unfavorable, the electricity production from our solar service offerings may be below our customers’ expectations, reducing the attractiveness of our offerings compared with traditional energy suppliers.

Utilities generally have substantially greater financial, technical, operational and other resources than we do. As a result of their greater size, utilities may be able to devote more resources to the research, development, promotion and sale of their products or respond more quickly to evolving industry standards and changes in market conditions than we can. Furthermore, these competitors are able to devote substantially more resources and funding to regulatory and lobbying efforts.

Utilities could also offer other value-added products or services that could help them compete with us even if the cost of electricity they offer is higher than ours. In addition, a majority of utilities’ sources of electricity are non-solar, which may allow utilities to sell electricity more cheaply than we can. Moreover, regulated utilities are increasingly seeking approval to “rate-base” their own residential solar and storage businesses. Rate-basing means that utilities would receive guaranteed rates of return for their solar and storage businesses. This is already commonplace for utility scale solar projects and commercial solar projects. While few utilities to date have received regulatory permission to rate-base residential solar or storage, our competitiveness would be significantly harmed should more utilities receive such permission because we do not receive guaranteed profits for our solar service offerings.

We also face competition from other residential solar service providers. Many of these competitors have a higher degree of brand name recognition, differing business and pricing strategies, and greater capital resources than we have, as well as extensive knowledge of our target markets. If we are unable to establish or maintain a consumer brand that resonates with customers, maintain high customer satisfaction, or compete with the pricing offered by our competitors, our sales and market share position may be adversely affected, as our growth is dependent on originating new customers. We also face competitive pressure from companies that may offer lower-priced consumer offerings than we do.

In addition, we compete with companies that are not regulated like traditional utilities but that have access to the traditional utility electricity transmission and distribution infrastructure. These power service companies are able to offer customers electricity supply-only solutions that are competitive with our solar service offerings on both price and usage of solar energy technology. This may limit our ability to attract customers, particularly those who wish to avoid long-term contracts or have an aesthetic or other objection to putting solar panels on their roofs.

Furthermore, we face competition from purely finance-driven nonintegrated competitors that subcontract out the installation of solar energy systems, from installation businesses (including solar partners) that seek financing from external parties, from large construction companies, and from electrical and other roofing companies. In addition, local installers that might otherwise be viewed as potential solar partners may gain market share by being able to be the first providers in new local markets. Finally, as declining prices for solar panels and related equipment has resulted in an increase in consumers’ purchasing, instead of leasing, solar systems, we face competition from companies that offer consumer loans for these solar panel purchases.

As the solar industry grows and evolves, we will continue to face existing competitors as well as new competitors who are not currently in the market (including those resulting from the consolidation of existing competitors) that achieve significant developments in alternative technologies or new products such as storage solutions, loan products, or other programs related to third-party ownership. Our failure to adapt to changing market conditions, to compete successfully with existing or new competitors and to adopt new or enhanced technologies could limit our growth and have a material adverse effect on our business and prospects.

A material drop in the retail price of utility-generated electricity or electricity from other sources would harm our business, financial condition, and results of operations.

Customer decisions to buy our solar energy systems are impacted by electricity costs. Decreases in the retail prices of electricity from utilities or other energy sources would harm our ability to offer competitive pricing and could harm our business. The price of electricity from utilities could decrease as a result of:

A reduction in utility electricity prices would make the purchase of our solar service offerings less attractive. If the retail price of energy available from utilities were to decrease due to any of these or other reasons, we would be at a competitive disadvantage. As a result, we may be unable to attract new customers and our growth would be limited.

We rely on net metering and related policies to offer competitive pricing to customers in all of our current markets, and changes to such policies may significantly reduce demand for electricity from our solar service offerings.

As of December 31, 2021, a substantial majority of states have adopted net metering policies. Net metering policies are designed to allow homeowners to serve their own energy loads using on-site generation. Electricity that is generated by a solar energy system and consumed on-site avoids a retail energy purchase from the applicable utility, and excess electricity that is exported back to the electric grid generates a retail credit within a homeowner’s monthly billing period. At the end of the monthly billing period, if the homeowner has generated excess electricity within that month, the homeowner typically carries forward a credit for any excess electricity to be offset against future utility energy purchases. At the end of an annual billing period or calendar year, utilities either continue to carry forward a credit, or reconcile the homeowner’s final annual or calendar year bill using different rates (including zero credit) for the exported electricity.

Utilities, their trade associations, and fossil fuel interests in the country are currently challenging net metering policies, and seeking to eliminate them, cap them, reduce the value of the credit provided to homeowners for excess generation, or impose charges on homeowners that have net metering. For example, on April 14, 2020, the New England Ratepayers Association filed a petition with FERC, asking it to assert exclusive federal jurisdiction over state net metering programs. Such a declaratory order, if granted, would have encouraged legal challenges to state net metering programs and could have reduced the bill credits customers receive for the electricity they export to the grid. On July 16, 2020, FERC dismissed the petition unanimously on procedural grounds, but at least one commissioner indicated that FERC could revisit the issue of net metering jurisdiction in the future.

California’s Public Utilities Commission (“CPUC”) has made changes to rate design for solar customers, such as adopting "time of use" rates with different electricity prices during peak and off peak hours, as well as modifications to the minimum bill for solar customers. The CPUC is revisiting its net metering policy in a proceeding that began in the third quarter of 2020 and is expected to conclude near the end of 2021 and not take effect until sometime in 2022. The California investor-owned utilities, along with other parties, are seeking to reduce the level of compensation for customer-owned generation and to impose grid access fees on solar customers. Similarly, certain California municipal utilities, which are not regulated by the CPUC and would not be governed by the CPUC's net metering policy, have also announced they plan to review their net metering policies.

Electric utility statutes and regulations and changes to such statutes or regulations may present technical, regulatory and economic barriers to the purchase and use of our solar service offerings that may significantly reduce demand for such offerings.

Federal, state and local government statutes and regulations concerning electricity heavily influence the market for our solar service offerings and are constantly evolving. These statutes, regulations, and administrative rulings relate to electricity pricing, net metering, consumer protection, incentives, taxation, competition with utilities, and the interconnection of homeowner-owned and third party-owned solar energy systems to the electrical grid. These statutes and regulations are constantly evolving. Governments, often acting through state utility or public service commissions, change and adopt different rates for residential customers on a regular basis and these changes can have a negative impact on our ability to deliver savings, or energy bill management, to customers.

In addition, many utilities, their trade associations, and fossil fuel interests in the country, which have significantly greater economic, technical, operational, and political resources than the residential solar industry, are currently challenging solar-related policies to reduce the competitiveness of residential solar energy. Any adverse changes in solar-related policies could have a negative impact on our business and prospects.

Regulations and policies related to rate design could deter potential customers from purchasing our solar service offerings, reduce the value of the electricity our systems produce, and reduce any savings that our customers could realize from our solar service offerings.

All states regulate investor-owned utility retail electricity pricing. In addition, there are numerous publicly owned utilities and electric cooperatives that establish their own retail electricity pricing through some form of regulation or internal process. These regulations and policies could deter potential customers from purchasing our solar service offerings. For example, some utilities in states such as Arizona and Utah have sought and secured rate design changes that reduce credit for residential solar exports to below the retail rate and impose new charges for rooftop solar customers. Utilities in additional states may follow suit. Such rate changes can include changing rates to charge lower volume-based rates—the rates charged for kilowatt hours of electricity purchased by a residential customer—while raising unavoidable fixed charges that a homeowner is subject to when they purchase solar energy from third parties, and levying charges on homeowners based on their point of maximum demand during a month (referred to as “demand charge”). For example, the Arizona Public Service Company offers residential demand charge rate plans, and, if our solar customers have subscribed to those plans, they may not realize typical savings from our offerings. These forms of rate design could adversely impact our business by reducing the value of the electricity our solar energy systems produce compared to retail net metering, and reducing any savings customers realize by purchasing our solar service offerings. These proposals could continue or be replicated in other states. In addition to changes in general rates charged to all residential customers, utilities are increasingly seeking solar-specific charges (which may be fixed charges, capacity-based charges, or other rate charges). Any of these changes could materially reduce the demand for our offerings and could limit the number of markets in which our offerings are competitive with electricity provided by the utilities.

Interconnection limits or circuit-level caps imposed by regulators may significantly reduce our ability to sell our solar service offerings in certain markets or slow interconnections, harming our growth rate and customer satisfaction scores.

Interconnection rules establish the circumstances in which rooftop solar will be connected to the electricity grid. Interconnection limits or circuit-level caps imposed by regulators may curb our growth in key markets. Utilities throughout the country have different rules and regulations regarding interconnection and some utilities cap or limit the amount of solar energy that can be interconnected to the grid. Our systems do not provide power to customers until they are interconnected to the grid.

Interconnection regulations are based on claims from utilities regarding the amount of solar energy that can be connected to the grid without causing grid reliability issues or requiring significant grid upgrades. Some states require the activation of some advanced inverter functionality to head off presumed grid reliability issues, which may require more expensive equipment and more oversight of the operation of the solar energy systems over time. As a result, these regulations may hamper our ability to sell our offerings in certain markets and increase our costs, adversely affecting our business, operating results, financial condition, and prospects. These advanced functions will become more commonplace as regions start to require 1547-2018 inverters, with activation of some advanced functions starting January 2022 in Maryland, Colorado and Arizona, with more to follow.

We and our solar partners depend on a limited number of suppliers of solar panels, batteries, and other system components to adequately meet anticipated demand for our solar service offerings. Any shortage, delay or component price change from these suppliers, or the acquisition of any of these suppliers by a competitor, could result in sales and installation delays, cancellations, and loss of market share.

We and our solar partners purchase solar panels, inverters, batteries, and other system components from a limited number of suppliers, making us susceptible to quality issues, shortages and price changes. If we or our solar partners fail to develop, maintain and expand our relationships with these or other suppliers, we may be unable to adequately meet anticipated demand for our solar service offerings, or we may only be able to offer our systems at higher costs or after delays. If one or more of the suppliers that we or our solar partners rely upon to meet anticipated demand ceases or reduces production, we may be unable to quickly identify alternate suppliers or to qualify alternative products on commercially reasonable terms, and we may be unable to satisfy this demand.

In particular, there is a limited number of suppliers of inverters, which are components that convert electricity generated by solar panels into electricity that can be used to power the home. For example, once we design a system for use with a particular inverter, if that type of inverter is not readily available at an anticipated price, we may incur delays and additional expenses to redesign the system. Further, the inverters on our solar energy systems generally carry only ten year warranties. If there is an inverter equipment shortage in a year when a substantial number of inverters on our systems need to be replaced, we may not be able to replace the inverters to maintain proper system functioning or may be forced to do so at higher than anticipated prices, either of which would adversely impact our business.

 Similarly, there is a limited number of suppliers of batteries. Once we design a system for use with a particular battery, if that type of battery is not readily available from our supplier, we may incur delays and additional expenses to install the system or be forced to redesign the system.

We undertake credit risk of default in payment from customer’s projects.

We may have to file liens to secure payments for certain consumer solar or battery projects but there is no assurance that such payments will be timely collected. We have also enhanced our collection efforts and undertaken various measures to collect outstanding payments from customers, builders and stemming from damages as a result of legal actions and other payments due to us.

Our projects may be subject to risks associated with construction, delays and other contingencies, which could have a material adverse effect on our reputation, business and the results of operations.

Historically, we have generated a significant portion of our revenue from servicing consumer and builder projects. We generally enter into contracts under which we act as the installation contractor for our customers in connection with the installation of their solar, battery and/or roofing systems. All essential costs are estimated at the time of entering into the contracts for a particular project, and are reflected in the overall fixed-price that we charge. These cost estimates are preliminary and may or may not be covered by contracts between us or any of our subcontractors, labor, suppliers or other parties to the project. In addition, we engage qualified and licensed subcontractors for the construction for some of these projects. Shortages of such skilled labor could significantly delay a project or otherwise increase our costs. Should miscalculations in project planning or delay in execution occur (including those due to unexpected increases in inflation, commodity prices or labor costs), we may not be able to achieve our expected margins or recover our costs.

In addition, our contracts may sometimes provide for performance milestones. Delays in supply of PV module or components, construction delays, pandemic delays, labor, unexpected performance problems in electricity generation or other events may cause us to fail to meet these performance criteria, resulting in unanticipated and severe revenue and earnings losses and financial penalties. If we are unable to complete the development of a solar project, or fail to meet one or more agreed target construction milestone dates, any agreed upon system-level capacity or energy output guarantees or warranties. As such, we may be subject to termination of such contracts or significant damages, penalties and/or other obligation under the agreements or other agreements relating to the projects (including obligations to repair, replace and/or supplement additional modules and balance of system materials for the projects), particularly if our liabilities are not capped under the terms of such agreements, and we may not be able to recover our investment in the project. The occurrence of any of these events could have a material adverse effect on our reputation, business and results of operations.

Our roofing and solar installers are subject to risks of injury.

We operate on various roofing surfaces that are typically one to three stories above ground. Our installers are trained in all applicable safety training programs and maintain fall protection whenever they are working at, or above, the mandated working height. Even with these precautions, there is always a risk of injury, including severe injuries and/or death from these operations. The Company attempts to minimize these risks through repeated safety training, safety programs, safety incentive programs, and appropriate disciplinary actions for failure to adhere to Company and/or local government safety protocols at these jobsites.

We operate a number of autos, vehicles, large trucks, forklifts, job site equipment and other machinery/tools which have the potential to cause injury and/or death to our installers and/or third parties. To attempt to prevent and minimize these risks, we engage third parties to conduct training, monitor safety and advise on safety process improvements to keep our employees, installers and third-parties as safe as possible. Even so, there still remains a risk of injuries, loss of life and resultant damage/costs/medical claims.

Risks Related to Our Operation in Phoenix

The Company’s investment in Phoenix Cars LLC and Phoenix Motorcars Leasing LLC (together, “Phoenix”) is highly risky. Following are material risks related to the investment.

Phoenix has never been profitable.

For the years ended December 31, 2020 and 2019, Phoenix’s unaudited combined net loss was $4.6 million and $6.0 million, respectively. For the year ended December 31, 2021, Phoenix’s audited net loss was $14.6 million.

Electric vehicles is a new industry, so Phoenix’s success cannot be assured.

The electric vehicle (EV) industry in the United States is small by comparison with the traditional automotive vehicle industry. In particular, the medium-duty electric vehicle business, in which Phoenix engages, is comprised of a relatively small number of companies. Unless the use of battery power for medium-duty vehicles gains wide acceptance, Phoenix’s business will become unsustainable. There are a number of obstacles to wide acceptance of Phoenix’s EVs, as follows:

Costs of electric vehicles are high in comparison with those of traditional vehicles powered by internal combustion engines or hybrids.

Phoenix’s EVs will not gain wide acceptance unless Phoenix can reduce manufacturing costs. Prices of Phoenix EVs range from$165,000 to $220,000, whereas prices of comparable traditional vehicles range from approximately $50,000 to $70,000. The cost difference is due to the incremental cost of electric drivetrain, including lithium-ion batteries, motors, inverter and control software, coupled with the relatively low volume of production, leading to higher overheads.

In addition, government subsidies and incentives, including those available in California, are important for the cost-competitiveness of Phoenix’s EVs, and Phoenix’s growth and prospects depend in part on the availability and amounts of these subsidies and incentives. Any reduction, elimination or discriminatory application of government subsidies and incentives because of budgetary challenges, policy changes, the reduced need for such subsidies and incentives due to the perceived success of electric vehicles, or other reasons may impair the cost-competitiveness of Phoenix’s EVs.

The range of Phoenix’s EVs is limited, compared with that of traditional vehicles.

Whereas traditional medium-duty vehicles may travel from 240 to 350 miles before refueling, Phoenix’s EVs have a maximum range of 160 miles and minimum recharging time of five to six hours. Currently, Phoenix’s EVs can be charged only at the owner’s location or select public charging locations using compatible charging equipment, further limiting the EVs to local use. Accordingly, potential customers needing vehicles with longer ranges or quicker turnaround of depleted fuel or electric energy supply may find Phoenix’s products relatively less attractive.

The demand for commercial electric vehicles depends, in part, on the continuation of current trends resulting from dependence on fossil fuels. Extended periods of low diesel or other petroleum-based fuel prices could adversely affect demand for Phoenix’s vehicles, which would adversely affect its business, prospects, financial condition and operating results.

We believe that much of the current and projected demand for commercial electric vehicles results from concerns about volatility in the cost of petroleum-based fuel, the dependency of the United States on oil from unstable or hostile countries, government regulations and economic incentives promoting fuel efficiency and alternative forms of energy, as well as the belief that climate change results in part from the burning of fossil fuels. If the cost of petroleum-based fuel decreased significantly, the outlook for the long-term supply of oil to the United States improves, the government eliminates or modifies its regulations or economic incentives related to fuel efficiency and alternative forms of energy, or if there is a change in the perception that the burning of fossil fuels negatively impacts the environment, the demand for commercial electric vehicles could be reduced, and our business and revenue may be harmed.

Diesel and other petroleum-based fuel prices have been extremely volatile, and we believe this continuing volatility will persist. Lower diesel or other petroleum-based fuel prices over extended periods of time may lower the perception in government and the private sector that cheaper, more readily available energy alternatives should be developed and produced. If diesel or other petroleum-based fuel prices remain at deflated levels for extended periods of time, the demand for commercial electric vehicles may decrease, which would have an adverse effect on our business, prospects, financial condition and operating results.

Phoenix’s growth depends upon the willingness of operators of commercial vehicle fleets to adopt electric vehicles and on its ability to produce, sell, and service vehicles that meet their needs. Operators’ willingness to acquire EV fleets often depends upon the cost to an operator in adopting EV technology, as compared to the cost of traditional vehicle technology.

Phoenix’s growth requires adoption of commercial vehicle operators to adopt EVs for their fleets and on Phoenix’s ability to produce, sell and service vehicles that meet their needs. EVs' use in the medium-duty commercial vehicle market is a relatively new development, particularly in the United States, and is characterized by rapidly changing technologies and evolving government regulation, industry standards, and customer views of the merits of using electric vehicles in their businesses. This process has been slow, as, without including the impact of government or other subsidies and incentives, the purchase prices for Phoenix’s EVs currently is higher than those for diesel-fueled vehicles. The relatively low price of oil has also hurt Phoenix’s over the last few years.

If the market for commercial electric vehicles does not develop as Phoenix expects, its business, prospects, financial condition and operating results will be impaired.

Phoenix must educate fleet managers regarding the economic benefits that Phoenix believes result over the life of its EVs. Phoenix believes that these benefits depend on the following:

If, in weighing these factors, operators of commercial vehicle fleets determine that there is no compelling business justification for purchasing commercial EVs, the market for commercial EVs may not develop as, or may develop more slowly than, Phoenix expects which would adversely affect Phoenix’s business, prospects, financial condition and operating results.

Phoenix’s current backlog consists entirely of orders for vehicles with a new drive system and a new chassis, entailing risks of fulfillment delays.

Phoenix is the process of releasing its Generation 3 drive system build, using a new battery supplier (a U.S. domestic company) and a thermal management cooling system. Also, all of Phoenix’s products are built on the Ford E-450 chassis. The 2021 model year chassis has changed significantly from the most recent, 2019 chassis, on which Phoenix built its previous years’ products. These changes require Phoenix’s engineering team to update the Generation 3 drive system to be compatible with both the 2019, as well as the 2021 chassis. Delays in deploying this new drive system or adapting to the new chassis would adversely affect production targets, impairing revenue and income expectations.

Some of Phoenix’s customers require its vehicles to pass Federal Transit Administration “Altoona” testing, and the failure of Phoenix’s vehicles to do so would adversely affect sales and revenue.

Phoenix plans to begin Altoona testing at the end of the second quarter of 2022 (pending availability for test slots); the tests are expected to last between three and six months. Production of the test vehicle has been completed and its going through pretest progress. Failure to complete testing in this timeframe would adversely affect order fulfillment, as well as future sales, to customers and potential customers that require successful completion of the test program.

All of Phoenix’s current range of products are built on Ford’s E-450 chassis. A decision by Ford to offer an electric version of this chassis, directly, would impact the viability of Phoenix’s current products.

Phoenix currently builds all its products on Ford’s E-450 chassis and is approved by Ford as an ‘electric Qualified Vehicle Modifier.’ Ford does not offer an electric version of this chassis, due to the relatively small market size for medium-duty electric vehicles. As volumes increase, there is a potential risk of Ford’s launching an electric version of Ford’s E-450 chassis directly from the factory, negating the need for Phoenix’s current range of products. Additionally, a shortage in the availability of this chassis would impact Phoenix’s capability to produce and fulfill customer’s orders in a timely manner.

Phoenix has a limited number of customers, with which Phoenix does not have long-term agreements, and expects that a significant portion of our future sales will be from a limited number of customers. The loss of any of these customers could materially harm Phoenix’s business.

A significant portion of Phoenix’s projected future revenue is expected to be generated from a limited number of customers. Phoenix has no contracts with customers that include long-term commitments that ensure future sales of vehicles. The loss of or a reduction in sales or anticipated sales to Phoenix’s most significant customers would have a material adverse effect on our business, prospects, financial condition and operating results.

Phoenix may face competition from global automotive manufacturers.

Phoenix competes with a number of commercial EV manufacturers, including those such as Chanje Energy and Rivian that are backed by global companies. In addition to Tesla, a number of traditional global automobile manufacturers, including BMW, Ford, General Motors, Mercedes Benz, and Nissan-Renault-Mitsubishi-Toyota, have entered the consumer EV business, and a few, including Tesla and Daimler have begun entry into the commercial EV market. It is possible that others in the consumer EV business, or heavy-duty EV manufacturers, could expand into the medium-duty EV business and compete with Phoenix. In addition, many of the aforementioned companies, along with others, such as Volvo, BYD, Hyundai, Honda, and Fiat participate in the hybrid business, which includes commercial vehicles that may compete with Phoenix. These companies have far greater resources, brand recognition, and distribution channels than Phoenix or the Company does, which could make it difficult for Phoenix to gain widespread market acceptance. There can be no assurance that Phoenix will be able to compete successfully with other market participants, and if Phoenix cannot, then its business could fail.

Phoenix currently has no long-term supply contracts that guarantee pricing, which exposes Phoenix to fluctuations in component, materials, and equipment costs. Substantial increases in these prices would increase operating costs, adversely affecting Phoenix’s business, prospects, financial condition and operating results.

Because Phoenix currently has no long-term supply contracts that guarantee pricing on key components including base chassis and drivetrain components (excluding batteries), Phoenix is exposed to risks of increases in prices of the raw materials, parts, and components, and equipment used in EV production. Substantial increases in such prices would increase our operating costs and could reduce our margins if we cannot recoup the increased costs through increased vehicle prices. Any attempts to increase the announced or expected prices of our vehicles in response to increased costs could be viewed negatively by our customers and could adversely affect our business, prospects, financial condition and operating results. Phoenix has a long-term contract with its current battery supplier, offering pricing guarantees for a three-year period. The contract also stipulates minimum order quantities for the term of the contract.

Disruption of supply or shortage of raw materials could harm Phoenix’s business.

Historically, we have experienced significant delivery delays and supply shortage with our BOM components, battery packs in particular. When encountered with supply disruption or shortage, our production plans and delivery schedules to our customers are to a large extent dictated by the timing of receiving these BOM components, or when a different supplier is fully qualified and customized into our product design. For example, COVID-19, including associated variants, has caused disruptions to and delays in our operations, including shortages and delays in the supply of certain parts, including semiconductors, materials and equipment necessary for the production of our vehicles, and the various internal designs and processes we have adopted in an effort to remedy or mitigate impacts of such disruptions and delays have resulted in higher costs. In addition, a growth in popularity of EVs without a significant expansion in battery cell production capacity could result in shortages which would result in increased materials costs to us, and would impact our projected manufacturing and delivery timelines, and adversely affect our business, prospects, financial condition, results of operations, and cash flows. Although we have worked diligently with our suppliers to mitigate the risks, we expect supply chain delays to continue to have a significant impact on our 2021 production and revenue and possibly thereafter. Any such supply interruption or shortage could materially adversely affect our business and operating results.

Phoenix’s business requires highly technically skilled personnel, for whom Phoenix must compete for employment.

Phoenix’s manufacturing and research and development require highly skilled electrical, mechanical, and software engineers. Competition for employment of such individuals is intense, and Phoenix’s ability to attract and retained and retaining them is essential to continuing its business. Growth of Phoenix’s business will depend upon its ability to compete for increasing numbers of such employees, and there can be no assurance that Phoenix will be able to do so.

Phoenix EVs use lithium-ion batteries, which, if not appropriately managed and controlled, have caught fire or released smoke and flames. Such events could result in liability under Phoenix’s warranties, for damage or injury, adverse publicity and a potential safety recall, any of which would hurt Phoenix’s prospects.

The battery packs in Phoenix’s EVs use lithium-ion cells, which, if not appropriately managed and controlled can rapidly release energy by venting smoke and flames that can ignite nearby materials. Highly publicized incidents of laptop computers and cell phones bursting into flames have focused attention on the safety of these cells. These events also have raised questions about the suitability of lithium-ion cells for automotive applications. There can be no assurance that a field failure of Phoenix’s battery packs will not occur, which would damage the vehicle or lead to personal injury or death that subject Phoenix to lawsuits. Furthermore, there is some risk of electrocution if individuals who attempt to repair battery packs do not follow applicable maintenance and repair protocols. Any such damage or injury would likely lead to adverse publicity and potentially a safety recall. Any such adverse publicity could adversely affect Phoenix’s business, prospects, financial condition and operating results.

Risks Related to Our Cryptocurrency Mining Services

The global cryptocurrency mining services market is highly competitive and fragmented with low barriers to market.

Although the market for providing services to cryptocurrency miners is new and evolving, the barriers to entry are quite low. Except for having the financial resources to set up a facility, no specialized technology or know-how required. Therefore, if cryptocurrency mining remains profitable, we expect additional competitors to enter the market, some of whom may have greater resources than we do.

The prices of Bitcoin and other cryptocurrencies have been fluctuating wildly in the last few months. If there is fewer people who want to conduct cryptocurrency mining operations due to the wild fluctuation, the demand for our services will decline.

The prices of cryptocurrencies have been fluctuating wildly in the last few months. Such fluctuation may make cryptocurrency mining less profitable. If the price of cryptocurrencies falls or does not increase, fewer people are likely to conduct cryptocurrency mining operations, which would reduce the demand for our services.

Blockchain technology and cryptocurrency are in the early stages of development and it is difficult to predict how the market for cryptocurrencies will develop.

Blockchain technology and cryptocurrency are in the early stages of development and it is difficult to predict how the market for cryptocurrencies will develop. There are significant factors which may inhibit the growth of these markets, including:

Any of these factors could significantly limit the growth of our business.

We need to access a large quantity of power at a reasonable cost in order to provide our cryptocurrency mining services; if we are unable to access such power sources, we will not be able to continue providing cryptocurrency mining services profitably.

We need to access a large quantity of power at a reasonable cost in order to provide our cryptocurrency mining services, and we do not have any long-term contract for the provision of power at specified prices. As competition in this area increases, we may not be able to access power at reasonable costs or at all. If we are unable to access new power sources, or the price of our current power sources significantly increase, we will not be able to continue providing cryptocurrency mining services profitably.

Risks Relating to Our Hemp and CBD Business

The hemp and CBD industries are evolving yet highly regulated and we must anticipate and respond to changes and risks.

In September 2019, the Company launched a hemp and Cannabidiol (“CBD”) businesses and as of the date of this annual report, our hemp and CBD businesses have no revenue derived. The hemp and CBD industries are not yet well- developed, and many aspects of the industries’ development and evolution cannot be accurately predicted. In addition, the hemp and CBD businesses are heavily regulated in the jurisdiction(s) where we carry on such businesses. Although the hemp and CBD businesses contribute nil to our total revenue, our hemp and CBD businesses are subject to various laws, regulations and guidelines by governmental authorities relating to, among other things, the manufacture, marketing, management, transportation, storage, sale, pricing and disposal of cannabis, U.S. hemp and cannabis-based products, and also including laws, regulations and guidelines relating to health and safety, insurance coverage, the conduct of operations and the protection of the environment. You should carefully consider that there are other risks that cannot be foreseen or are not described herein, which could affect Company’s business and financial performance.

DEA Regulation of CBD varies depending on the concentration of THC.

Under Drug Enforcement Administration (DEA) regulations, marijuana is a Schedule 1 drug not approved as a medication in the United States; however, hemp has been distinguished from marijuana under the definition revised in 2018. Hemp is defined as the plant Cannabis sativa L. and any part of that plant — including the seeds and all derivatives, extracts, cannabinoids, isomers, acids, salts, and salts of isomers, whether growing or not — with a THC concentration of not more than 0.3 percent on a dry weight basis.

U.S. Food and Drug Administration (FDA) Regulations do not permit CBD as a food additive or dietary supplement.

Analysis of the potential for regulatory impact on any type of CBD product is fact-specific and requires close evaluation of several factors, including the type of product (e.g., food, dietary supplement, or cosmetic), product’s labeling, and the existing compliance structure of the product developer or manufacturer. The FDA regulates CBD if it is used as a food additive, a dietary supplement or in cosmetic products, or if it is advertised as a drug.

Rapidly changing state laws may impose further restrictions on CBD products.

Where CBD products are sold or manufactured, it is important to review applicable state law to determine any further restrictions on CBD. For instance, the North Carolina Department of Agriculture and Consumer Services recently announced it would send letters to businesses notifying them that the sale of CBD in food, drinks and animal food violates state and federal law. Further, in February 2019, Maine and New York announced that restaurants and other retailers may not sell products containing CBD and that the states would begin enforcing these restrictions. These state restrictions may significantly impact overall sales of CBD products as the regulatory landscape continues to evolve.

Avoid certain advertising and labeling claims for CBD products.

Marketing claims about the therapeutic benefits of CBD may inadvertently subject CBD product manufacturers to FDA’s drug regulations. Claims that CBD can treat or mitigate a disease or condition, for instance, may run afoul of FDA’s position on CBD product marketing. To date, the FDA has approved only one drug directly using CBD - Epidiolex - which treats two rare forms of childhood epilepsy. The FDA has not determined that CBD is safe or effective for treating any other particular disease or condition. Accordingly, companies should avoid making claims that CBD will aid in the treatment of any particular disease or condition or provide any particular health benefits. FDA further clarified that it will continue to aggressively pursue companies marketing CBD products with “egregious and unfounded claims that are aimed at vulnerable populations.”

Federal regulation of CBD will continue to evolve.

The FDA’s position on CBD is not static, and potential investors should continue to monitor the evolving federal landscape. The FDA recently held a public hearing to obtain scientific data and information about the safety, manufacturing, product quality, marketing, labeling and sale of products containing cannabis or cannabis-derived compounds. The FDA also announced that it is forming a high-level internal agency working group to explore potential pathways for dietary supplements and/or conventional foods containing CBD to be lawfully marketed. The group will consider what statutory or regulatory changes might be needed and the likely impact of such marketing on public health. As stakeholders weigh in on this issue, FDA’s position on this topic likely will continue to evolve.

Risks Related to Our Alfalfa Business

Covid-19 continues to impact on alfalfa hay transportation.

With Asia’s increasing demand for American alfalfa hay, we have recognized the importance of exporting to the Asian market. However, the uncertainty around the coronavirus has disrupted global markets and the U.S. market has not been immune. Major oceanic carriers have reduced the frequency of their shipments, disrupting our supply chain. This required U.S. exporters to reschedule shipments and work to find boat space for new shipments. Fortunately, there is sustained demand from major importing countries, but logistics will be a challenge in the coming months.

U.S.-China trade disruption remains unclear.

The outcome of the U.S.-China trade war remains unclear. There might be future disruptions in the market with potential for tariffs being set on our products. This will affect the Chinese demand for our products if our products become more expensive than Chinese local producers when tariffs are added to our prices.

Weather condition may lead to decline in hay production.

Weather conditions are a huge factor affecting alfalfa hay production. Increasingly random weather patterns due to global warming could post a potential risk to production levels.

Risks Related to Our Ordinary Shares

Our ordinary shares may be delisted under the Holding Foreign Companies Accountable Act if the PCAOB is unable to inspect our auditors. The delisting of our ordinary shares, or the threat of their being delisted, may materially and adversely affect the value of your investment. Furthermore, on June 22, 2021, the U.S. Senate passed the Accelerating Holding Foreign Companies Accountable Act, which, if enacted, would amend the HFCA Act and require the SEC to prohibit an issuer’s securities from trading on any U.S. stock exchanges if its auditor is not subject to PCAOB inspections for two consecutive years instead of three.

The Holding Foreign Companies Accountable Act, or the HFCA Act, was enacted on December 18, 2020. The HFCA Act states if the SEC determines that a company has filed audit reports issued by a registered public accounting firm that has not been subject to inspection by the PCAOB for three consecutive years beginning in 2021, the SEC shall prohibit such ordinary shares from being traded on a national securities exchange or in the over the counter trading market in the U.S.

On March 24, 2021, the SEC adopted interim final rules relating to the implementation of certain disclosure and documentation requirements of the HFCA Act. A company will be required to comply with these rules if the SEC identifies it as having a “non-inspection” year under a process to be subsequently established by the SEC. The SEC is assessing how to implement other requirements of the HFCA Act, including the listing and trading prohibition requirements described above. Furthermore, on June 22, 2021, the U.S. Senate passed the Accelerating Holding Foreign Companies Accountable Act, which, if enacted, would amend the HFCA Act and require the SEC to prohibit an issuer’s securities from trading on any U.S. stock exchanges if its auditor is not subject to PCAOB inspections for two consecutive years instead of three. On September 22, 2021, the PCAOB adopted a final rule implementing the HFCA Act, which provides a framework for the PCAOB to use when determining, as contemplated under the HFCA Act, whether the PCAOB is unable to inspect or investigate completely registered public accounting firms located in a foreign jurisdiction because of a position taken by one or more authorities in that jurisdiction. On December 2, 2021, the SEC issued amendments to finalize rules implementing the submission and disclosure requirements in the HFCA Act. The rules apply to registrants that the SEC identifies as having filed an annual report with an audit report issued by a registered public accounting firm that is located in a foreign jurisdiction and that PCAOB is unable to inspect or investigate completely because of a position taken by an authority in foreign jurisdictions. On December 16, 2021, the PCAOB issued a Determination Report which found that the PCAOB is unable to inspect or investigate completely registered public accounting firms headquartered in: (i) China, and (ii) Hong Kong.

Our current independent accounting firm, Marcum Bernstein & Pinchuk LLP, whose audit report is included in this annual report on Form 10-K, is headquartered in Manhattan, New York, and was not included in the list of PCAOB Identified Firms in the PCAOB December Release

However, given that all PCAOB-registered firms in China were included on that list, our ability to retain an auditor subject to PCAOB inspection and investigation may depend on the relevant U.S. and PRC regulators reaching an agreement to permit these inspections and investigations. Recent developments with respect to audits of companies with Hong Kong operations, such as SPI, create uncertainty about the ability of SPI’s auditor to fully cooperate with the PCAOB’s request for audit work papers without the approval of the Chinese authorities. The PCAOB has not requested Marcum Bernstein & Pinchuk LLP to provide the copies of these audit working papers and as a result, Marcum Bernstein & Pinchuk LLP has not sought permission from the Chinese authorities to provide copies of these materials to the PCAOB, but there is no assurance that they would be able to obtain such permission. More broadly, the PCAOB entered into a Memorandum of Understanding on Enforcement Cooperation with the CSRC and the PRC Ministry of Finance, which established a cooperative framework between the parties for the production and exchange of audit documents relevant to investigations undertaken by the PCAOB in the PRC or by the CSRC or the PRC Ministry of Finance in the United States. The PCAOB continues to be in discussions with the CSRC and the PRC Ministry of Finance to permit joint inspections of the PCAOB-registered audit firms that audit Chinese companies that trade on U.S. exchanges. However, in the PCAOB December 2021 Release, the PCAOB identified problems in implementing these agreements and a lack of cooperation. Accordingly, we can offer no assurance that we will be able to retain an auditor that would allow us to avoid a trading prohibition for our securities under the HFCA Act.

In addition to the issues under the HFCA discussed above, the PCAOB’s inability to conduct inspections in China and Hong Kong prevents it from fully evaluating the audits and quality control procedures of the independent registered public accounting firm. Our current independent registered public accounting firm, Marcum Bernstein & Pinchuk LLP, is headquartered in Manhattan, New York, and has been inspected by the PCAOB on a regular basis with the last inspection in 2018 and an ongoing inspection that started in November 2020. However, as noted above, recent developments create uncertainty as to the PCAOB’s continued ability to conduct inspections of our independent accounting firm, Marcum Bernstein & Pinchuk LLP.

We have significant “equity overhang” which could adversely affect the market price of our Shares and impair our ability to raise additional capital through the sale of equity securities.

As of the date of this annual report, we had 26,376,783 ordinary shares outstanding, including 4,903,204, ordinary shares, or approximately 18.59% of our total ordinary shares outstanding, held by Mr. Xiaofeng Peng, our director, executive chairman of the board of directors and chief executive officer. The possibility that substantial amounts of our outstanding ordinary shares may be sold by Mr. Xiaofeng Peng or the perception that such sales could occur, or “equity overhang,” could adversely affect the market price of our ordinary shares, and could impair our ability to raise additional capital through the sale of equity securities in the future.

We are subject to litigation risks, including securities class actions and shareholder derivative actions, which may be costly to defend and the outcome of which is uncertain.

 From time to time, we are subject to legal claims, with and without merit, that may be costly, and which may divert the attention of our management and our resources in general. In addition, our solar projects may be subject to litigation or other adverse proceedings that may adversely impact our ability to proceed with construction or grid connection or sell a given project, which would adversely affect our ability to recognize revenue with respect to such project. We are currently involved in various legal proceedings. See “Item 1. Business —Legal Proceedings.” The results of complex legal proceedings are difficult to predict. Lawsuits filed against us may assert types of claims that, if resolved against us, could give rise to substantial damages, and an unfavorable outcome or settlement of one or more of these lawsuits, or any future lawsuits, could have a material adverse effect on our business, financial condition, or results of operations. Even if these lawsuits are not resolved against us, the costs of defending such lawsuits may not be covered by our insurance policies. We cannot assure you that additional litigation will not be filed against us in the future.

It may be difficult to effect service of process on, or to enforce any judgments obtained against us, our directors, or our senior management members.

There is no statutory enforcement in the Cayman Islands of judgments obtained in the federal or state courts of the United States (and the Cayman Islands are not a party to any treaties for the reciprocal enforcement or recognition of such judgments). However, such a judgment will generally be recognized and enforced at common law by the courts of the Cayman Islands, without any re-examination or re-litigation of the merits of the case, by an action commenced on the foreign judgment debt, provided that: (a) the foreign court had jurisdiction over the parties to the dispute; (b) the judgment is for a liquidated sum; (c) the judgment is final, conclusive and not subject to appeal; (d) the judgment is not of a public, revenue or penal nature; (e) the judgment was not obtained by fraud or in proceedings contrary to natural justice; (f) the enforcement of the judgment would not be contrary to Cayman Islands public policy; (g) the judgment is not inconsistent with sections 91 or 92 of the Trusts Act (as revised) of the Cayman Islands; (h) the process by which the judgment is enforced is not barred under laws relating to the prescription and limitation of actions; and (i) the judgment is not inconsistent with a Cayman Islands judgment in respect of the same cause or point at issue between the same parties.

However, the Cayman Islands courts are unlikely to enforce a judgment obtained from the U.S. courts under civil liability provisions of the U.S. federal securities law if such judgment is determined by the courts of the Cayman Islands to give rise to obligations to make payments that are penal or punitive in nature. Because such a determination has not yet been made by a court of the Cayman Islands, it is uncertain whether such civil liability judgments from U.S. courts would be enforceable in the Cayman Islands. 

Our shareholders may experience future dilution.

Our amended and restated memorandum and articles of association permits our board of directors, without shareholder approval, to authorize the issuance of preferred shares. The board of directors may classify or reclassify any preferred shares to set the preferences, rights and other terms of the classified or reclassified shares, including the issuance of preferred shares that have preference rights over our ordinary shares with respect to dividends, liquidation and voting rights. Furthermore, substantially all of our ordinary shares for which our outstanding stock options are exercisable are, once they have been purchased, eligible for immediate sale in the public market.

We may from time to time distribute rights to our shareholders, including rights to acquire our securities. However, we cannot make these rights available in the United States unless we register the rights and the securities to which the rights relate under the Securities Act or an exemption from the registration requirements is available. We are under no obligation to file a registration statement with respect to any such rights or securities or to endeavor to cause a registration statement to be declared effective. Moreover, we may not be able to establish an exemption from registration under the Securities Act. Accordingly, you may be unable to participate in our rights offerings and may experience dilution in your holdings.

The issuance of additional shares in our capital or the exercise of stock options or warrants could be substantially dilutive to your shares and may negatively affect the market price of our ordinary shares.

The price of our securities has been and may continue to be highly volatile.

The price of our ordinary shares has been and may continue to be subject to wide fluctuations in the future in response to many events or factors, including those discussed in the preceding risk factors relating to our operations, as well as:

Any of these factors may result in large and sudden changes in the volume and price at which our ordinary shares will trade. We cannot give any assurance that these factors will not occur in the future again. In addition, the securities market has from time to time experienced significant price and volume fluctuations that are not related to the operating performance of particular companies. These market fluctuations may also have a material adverse effect on the market price of our ordinary shares. In the past, following periods of volatility in the market price of their stock, many companies have been the subject of securities class action litigation. If we become involved in similar securities class action litigation in the future, it could result in substantial costs and diversion of our management’s attention and resources and could harm our stock price, business, prospects, financial condition and results of operations.

If we fail to meet the applicable listing requirements, NASDAQ may delist our ordinary shares from trading on its exchange in which case the liquidity and market price of our securities could decline and our ability to raise additional capital would be adversely affected.

Our ordinary shares are currently listed for trading on the NASDAQ Global Select Market. If we remain listed, there are a number of requirements that must be met in order for our ordinary shares to remain listed on the NASDAQ Global Select Market, and the failure to meet any of these listing standards could result in the delisting of our ordinary shares from NASDAQ. We cannot assure you that we will be able to timely file all required reports or comply with all other NASDAQ Listing Rules at all times in the future, or regain compliance in a timely manner in case of a default and avoid any subsequent adverse action taken by the Listing Qualifications Department, including but not limited to delisting.

Our articles of association contain anti-takeover provisions that could prevent a change in control even if such takeover is beneficial to our shareholders.

Our articles of association contain provisions that could delay, defer or prevent a change in control of us that could be beneficial to our shareholders. These provisions could also discourage proxy contests and make it more difficult for you and other shareholders to elect directors and take other corporate actions. As a result, these provisions could limit the price that investors are willing to pay for the ordinary shares. These provisions might also discourage a potential acquisition proposal or tender offer, even if the acquisition proposal or tender offer is at a price above the then current market price of our ordinary shares. These provisions provide that our board of directors has authority, without any further action by our shareholders, to issue preferred shares in one or more series and to fix their designations, powers, preferences, privileges, and relative participating, optional or special rights and the qualifications, limitations or restrictions, including dividend rights, conversion rights, voting rights, terms of redemption and liquidation preferences, any or all of which may be greater than the rights associated with the ordinary shares. The board of directors may decide to issue such preferred shares quickly with terms calculated to delay or prevent a change in control of us or make the removal of our management more difficult. If the board of directors decides to issue such preferred shares, the price of our ordinary shares may fall and the voting and other rights of holders of our ordinary shares may be materially adversely affected.

You may not receive dividends or other distributions on our ordinary shares and you may not receive any value for them, if it is illegal or impractical to make them available to you.

Under Cayman Islands law, we may only pay dividends out of our profits or share premium account subject to our ability to pay our debts as they fall due in the ordinary course of our business. Our ability to pay dividends may therefore depend on our ability to generate sufficient profits. We cannot give any assurance that we will declare dividends of any amounts, at any rate or at all in the future. We have not paid any dividends in the past. Future dividends, if any, will be paid at the discretion of our board of directors, subject to requirements under Cayman Islands law and our memorandum and articles of association, as amended and restated from time to time, and will depend upon our future operations and earnings, capital expenditure requirements, general financial conditions, legal and contractual restrictions and other factors that our board of directors may deem relevant.

We are treated as a U.S. corporation for U.S. federal tax purposes.

Due to the circumstances of our formation and the application of Section 7874(b) of the United States Internal Revenue Code of 1986, as amended (the “Code”), we are treated as a U.S. corporation for all purposes of the Code. As a result, we are subject to U.S. federal corporate income tax on our worldwide income. In addition, if we pay dividends to a Non-U.S. Holder, as defined in the discussion “Item 10. Additional Information—E. Taxation—U.S. Federal Income Taxation,” U.S. income tax will be withheld at the rate of 30%, or, subject to certain conditions, such lower rate as may be provided in an applicable income tax treaty. Each investor should consult its own tax adviser regarding the U.S. federal income tax consequences of holding the ordinary shares in its particular circumstances.

Risks Related to Our International Operations

We are subject to risks associated with foreign currency exchange rates, fluctuations of which may negatively affect our revenue, cost of goods sold and gross margins and could result in exchange losses.

We currently operate in a number of jurisdictions including the U.S., Japan, U.K., Greece, Italy, Australia and Canada, and our local operations are generally conducted in the functional currency of the home jurisdiction. The FIT and other subsidies granted are also denominated in local currencies. Thus, we deal on a regular basis in several currencies concurrently, which exposes us to significant currency exchange risks. Any increased costs or reduced revenue as a result of foreign exchange rate fluctuations could adversely affect our profit margins. The fluctuation of foreign exchange rates also affects the value of our monetary and other assets and liabilities denominated in local currencies. Generally, an appreciation of the U.S. dollar against the relevant local currencies could result in a foreign exchange loss for assets denominated in such local currencies and a foreign exchange gain for liabilities denominated in such local currencies. Conversely, a devaluation of the U.S. dollar against the relevant local currencies could result in a foreign exchange gain for assets denominated in such local currencies and a foreign exchange loss for liabilities denominated in such local currencies.

We may also expand into emerging markets, some of which may have an uncertain regulatory environment relating to currency policy. Conducting business in such emerging markets could increase our exposure to foreign exchange risks. Although we access a variety of financing solutions that are tailored to the geographic location of our projects and to local regulations, we have not entered into any hedging transactions to reduce the foreign exchange risks, but may do so in the future when appropriate. However, if we decide to hedge our foreign exchange exposure in the future, we cannot assure you that we will be able to reduce our foreign currency risk exposure in an effective manner, at reasonable costs, or at all.

The ongoing debt crisis in the Eurozone and market perceptions concerning the instability of the Euro and the European economy could adversely affect our business, results of operations and financing.

Concerns persist regarding the debt burden of certain Eurozone countries and their ability to meet future financial obligations, the overall stability of the Euro and the suitability of the Euro as a single currency given the diverse economic and political circumstances in individual Eurozone countries. These concerns or market perceptions concerning these and related issues could adversely affect the value of our Euro-denominated assets and obligations and lead to future economic slowdowns.

General Risk Factors

Misconduct and errors by our employees could harm our business and reputation.

We are exposed to many types of operational risks, including the risk of misconduct, errors and fraud by our employees and key management personnel. Our training, resources, technologies and fraud detection tools may be insufficient to accurately detect and prevent fraud. Significant increases in fraudulent activity could negatively impact our brand and reputation, which could increase our costs and expenses. High profile fraudulent activity could even lead to regulatory intervention, and may divert our management’s attention and cause us to incur additional expenses and costs. If any of the foregoing were to occur, our results of operations and financial condition could be materially and adversely affected.

Failure to manage our evolving business could have a material adverse effect on our business, prospects, financial condition and results of operations.

We intend to expand our business within our existing markets and in a number of selected new locations in the future. We also intend to expand our global project development business in the future. As our operations evolve, we expect to encounter additional challenges in our internal management, construction contracting management, investment and acquisition management, project management, project funding infrastructure and financing capabilities. Our existing operations, personnel, systems and internal control may not be adequate to support our business expansion and may require new investments in our internal management infrastructure. To manage the future growth of our operations, we will be required to improve our administrative, operational and financial systems, procedures and controls, and maintain, expand, train and manage a growing number of employees.

 We may continue to conduct acquisitions and enter into joint ventures, investments or other strategic alliances which may be unsuccessful.

We may continue to grow our operations through acquisitions, as well as joint ventures or other strategic alliances when appropriate opportunities arise. Such acquisitions, joint ventures and strategic alliances may expose us to additional operational, regulatory, market and geographical risks as well as risks associated with additional capital requirements and diversion of management attention. In particular, any future strategic alliances may expose us to the following risks:

The materialization of any of these risks could have a material adverse effect on our business, financial condition and results of operations.

Our failure to protect our intellectual property rights may undermine our competitive position, and litigation to protect our intellectual property rights may be costly.

We rely primarily on trade secrets, know-how and other proprietary information to protect our intellectual property. Nevertheless, these afford only limited protection and the actions we take to protect our intellectual property rights may not be adequate to provide us with meaningful protection or commercial advantage. Third parties may be able to use the technologies that we have developed and compete with us, which could have a material adverse effect on our business, financial condition or results of operations. Our failure to protect our intellectual property and proprietary rights may undermine our competitive position. Third parties may infringe or misappropriate our proprietary technologies or other intellectual property and proprietary rights. Policing the unauthorized use of proprietary technology can be difficult and expensive. In particular, the laws and enforcement procedures certain markets where we operate are uncertain or do not protect intellectual property rights to the same extent as do the laws and enforcement procedures of the United States. We may need to resort to court proceedings to enforce our intellectual property rights in the future. Litigation relating to our intellectual property might result in substantial costs and diversion of resources and management attention away from our business. An adverse determination in any such litigation will impair our intellectual property rights and adversely affect our business, prospects and reputation.

We may be exposed to infringement or misappropriation claims by third parties which, if determined adversely to us, could cause us to pay significant damage awards.

Our success depends largely on our ability to use and develop our technology and know-how without infringing the intellectual property rights of third parties. The validity and scope of claims relating to solar technology involve complex scientific, legal and factual questions and analysis and, therefore, may be highly uncertain. As we continue to expand internationally, we face a heightened risk of becoming the subject of claims for intellectual property infringement. We may be subject to litigation involving claims of patent infringement or violation of intellectual property rights of third parties. An adverse determination in any such litigation or proceedings against us could subject us to significant liabilities to third parties, including requiring us to seek licenses from third parties, to pay ongoing royalties or to pay monetary and punitive damages. Protracted litigation could also result in our customers or potential customers deferring or limiting their procurement of our PV solutions until resolution of such litigation, which could result in losses and adversely affect our reputation and results of operations.

The preparation of our consolidated financial statements in accordance with U.S. generally accepted accounting principles requires us to make estimates, judgments and assumptions that may ultimately prove to be incorrect.

The accounting estimates and judgments that management must make in the ordinary course of business affect the reported amounts of assets and liabilities at the date of the consolidated financial statements and the reported amounts of revenue and expenses during the periods presented. If the underlying estimates are ultimately proven to be incorrect, subsequent adjustments could have a material adverse effect on our operating results for the period or periods in which the change is identified.

Our business and financial results may be materially adversely affected by the current COVID-19 pandemic outbreak.

The pandemic of a novel coronavirus (COVID-19) has resulted in a widespread health crisis that has adversely affected the economies and financial markets worldwide. Government efforts to contain the spread of the coronavirus through lockdowns of cities, business closures, restrictions on travel and emergency quarantines, among others, and responses by businesses and individuals to reduce the risk of exposure to infection, including reduced travel, cancellation of meetings and events, and implementation of work-at- home policies, among others, have caused significant disruptions to the global economy and normal business operations across a growing list of sectors and countries.

Our operating results substantially depend on revenues derived from sales of PV project assets, provision of electricity, roofing and solar system installation and our Australian subsidiary’s trading of PV components. As the COVID-19 spread continues, the measures implemented to curb the spread of the virus have resulted in supply chain disruptions, insufficient work force and suspended manufacturing and construction works for solar industry. One or more of our customers, partners, service providers or suppliers may experience financial distress, delayed or defaults on payment, file for bankruptcy protection, sharp diminishing of business, or suffer disruptions in their business due to the outbreak. These preventative measures have also impacted our daily operations. The efforts enacted to control COVID-19 have placed heavy pressure on our marketing and sales activities. We continue to assess the related risks and impacts COVID-19 pandemic may have on our business and our financial performance. In light of the rapidly changing situation across different countries and regions, it remains difficult to estimate the duration and magnitude of COVID-19 impact. Until such time as the COVID-19 pandemic is contained or eradicated and global business return to more customary levels, our business and financial results may be materially adversely affected.

Our business could be negatively impacted by cybersecurity threats, attacks and other disruptions.

We face advanced and persistent attacks on our information infrastructure where we manage and store various proprietary information and sensitive/confidential data relating to our operations. These attacks may include sophisticated malware (viruses, worms, and other malicious software programs) and phishing emails that attack our products or otherwise exploit any security vulnerabilities. These intrusions sometimes may be zero-day malware that are difficult to identify because they are not included in the signature set of commercially available antivirus scanning programs. Experienced computer programmers and hackers may be able to penetrate our network security and misappropriate or compromise our confidential information or that of our customers or other third-parties, create system disruptions, or cause shutdowns. Additionally, sophisticated software and applications that we produce or procure from third-parties may contain defects in design or manufacture, including “bugs” and other problems that could unexpectedly interfere with the operation of the information infrastructure. A disruption, infiltration or failure of our information infrastructure systems or any of our data centers as a result of software or hardware malfunctions, computer viruses, cyber-attacks, employee theft or misuse, power disruptions, natural disasters or accidents could cause breaches of data security, loss of critical data and performance delays, which in turn could adversely affect our business.

Security breaches of confidential customer information or confidential employee information may adversely affect our business.

Our business requires the collection, transmission and retention of customer and employee data, and other personally identifiable information, in various information technology systems that we maintain and in those maintained by third parties with whom we contract to provide services. The integrity and protection of that customer and employee data is critical to us. The information, security and privacy requirements imposed by governmental regulation are increasingly demanding. Our systems may not be able to satisfy these changing requirements and customer and employee expectations, or may require significant additional investments or time in order to do so. A breach in the security of our information technology systems or those of our service providers could lead to an interruption in the operation of our systems, resulting in operational inefficiencies and a loss of profits. Additionally, a significant theft, loss or misappropriation of, or access to, customers’ or other proprietary data or other breach of our information technology systems could result in fines, legal claims or proceedings.

The costs of our operations may exceed our estimates due to factors outside of our control, such as labor shortages or external price increases, and we may be unable to pass those costs to our customers, which would negatively impact our financial results.

We depend on our employees and contracted grow operations teams to grow and distribute our products to our customers. We rely on access to competitive, local labor supply, including skilled and unskilled positions, to operate our business consistently and reliably. Any labor shortage, caused by the COVID-19 pandemic or other factors, and any disruption in our ability to hire workers would negatively affect our operations and financial condition. If we experience a sustained labor shortage, we may need to increase wages to attract workers, which would increase our costs of growing our products. Furthermore, if the prices of our raw materials, utilities or distributing our products were to increase, including due to inflationary pressures, we may be unable to pass those increased costs on to our customers. If we are unable to do so, our gross margin would decline, and our financial results would be negatively impacted.