OEG Orbital Energy Group Inc

Notes to the Condensed Consolidated Financial Statements

(Unaudited)

Nature of Operations

Orbital Energy Group, Inc. (Orbital Energy Group, "OEG," "The Company") is a diversified infrastructure services company serving customers in the electric power, telecommunications, and renewable markets. The Company’s reportable segments are the Electric Power segment, the Telecommunications segment, and the Renewables segment. In  December 2021, the Company announced the planned divestiture of its previously reported Integrated Energy Infrastructure Solutions and Services segment. 

The Electric Power segment consists of Front Line Power Construction, LLC based in Houston, Texas (acquired November 17, 2021), Orbital Power, Inc. based in Dallas, Texas, (began operations in Q1 2020) and Eclipse Foundation Group based in Gonzales, Louisiana (began operations in Q1 2021). The segment provides comprehensive infrastructure solutions to customers in the electric power industry. Services performed by Front Line Power and Orbital Power, Inc. generally include but are not limited to the engineering, design, installation, upgrade, repair and maintenance of electric power transmission and distribution infrastructure and substation facilities as well as emergency restoration services. Eclipse Foundation Group, which began operations in  January 2021, is a drilled shaft foundation construction company that specializes in providing services to the electric transmission and substation, industrial, telecommunication and disaster restoration market sectors, with expertise performing services in water, marsh and rock terrains.

The Telecommunications segment is made up of Gibson Technical Services, Inc. (“GTS”) (acquired  April 13, 2021) and subsidiaries. GTS is an Atlanta-based telecommunications company providing diversified telecommunications services nationally since 1990 and is the parent of IMMCO, Inc., Full Moon Telecom, LLC, and Coax Fiber Solutions, LLC. IMMCO, Inc. (acquired  July 28, 2021), which includes two Indian subsidiaries, is an Atlanta-based, full-service telecom engineering and network design company providing diversified engineering services and customized software solutions to a global customer base since 1992. Full Moon Telecom, LLC (acquired  October 22, 2021) is a Florida-based telecommunications service provider that offers an extensive array of wireless service capabilities and experience including Layer 2/Layer 3 Transport, Radio Access Network (“RAN”) Integration, test and turn-up of Small Cell systems and Integration/Commissioning of Distributed Antenna (“DAS”) systems. Coax Fiber Solutions, LLC (acquired March 7, 2022), is based in Georgia. Founded in 2016, Coax Fiber Solutions is a GDOT Certified contractor specializing in Aerial Installation, directional drilling, trenching, plowing, and missile crews for telecommunications, power, gas, water, CCTV, ATMS, and traffic signal cable installation.

Basis of Presentation

The accompanying interim unaudited condensed consolidated financial statements have been prepared in accordance with accounting principles generally accepted in the United States of America and the rules and regulations of the United States Securities and Exchange Commission for interim financial information, which includes condensed consolidated financial statements. Accordingly, they do not include all the information and notes necessary for a comprehensive presentation of financial position and results of operations and should be read in conjunction with the Company's Annual Report on Form 10-K for the year ended December 31, 2021. The Condensed Consolidated Balance Sheet as of  December 31, 2021 has been derived from the audited financial statements as of that date included in the Company's Annual Report on Form 10-K for the year ended December 31, 2021.

It is management's opinion that all material adjustments (consisting of normal recurring adjustments) have been made, which are necessary for a fair financial statement presentation. All intercompany accounts and transactions have been eliminated in consolidation. The results for the interim period are not necessarily indicative of the results to be expected for the remaining quarters or year ending December 31, 2022.

(1) Restrictions on cash at March 31, 2022 and March 31, 2021 relate to collateral for several bank-issued letters of credit for contract guaranties. 

Use of Estimates

The preparation of financial statements in conformity with accounting principles generally accepted in the United States of America requires management to make estimates and assumptions that affect the reported amounts of assets and liabilities, disclosure of contingent assets and liabilities at the date of the financial statements, and the reported amounts of revenues and expenses during the reporting period. Actual results could differ from those estimates. Significant estimates include estimates used to record purchase price allocation for the Company's acquisitions, fair value measurements used in goodwill impairment tests, impairment estimations of long-lived assets, revenue recognition on cost-to-cost type contracts, allowances for uncollectible accounts, valuations of non-cash capital stock issuances, estimates of the incremental borrowing rate for long-term leases, fair value estimates and the valuation allowance on deferred tax assets. The Company bases its estimates on historical experience and on various other assumptions that are believed to be reasonable in the circumstances, the results of which form the basis for making judgments about the carrying values of assets and liabilities that are not readily apparent from other sources. Actual results  may differ from these estimates under different assumptions or conditions.

Reclassifications

Certain reclassifications have been made to the 2021 classifications in order to conform to the 2022 presentation.

Company Conditions and Sources of Liquidity

The Company has experienced net losses and cash outflows from cash used in operating activities over the past years. As of and for the three months ended March 31, 2022, the Company had an accumulated deficit of $248.5 million, loss from continuing operations of $36.7 million, and net cash used in operating activities of $1.6 million.

As of March 31, 2022, the Company had cash and cash equivalents of $20.9 million available for working capital needs and planned capital asset expenditures and a working capital deficit of $65.1 million, including current maturities of debt. These factors initially raise substantial doubt about our ability to continue as a going concern, but this doubt has been alleviated by the Company’s plans to raise sufficient capital to meet our current obligations over the next twelve months, in addition to the expected recovery of our assets to satisfy liabilities in the normal course of business.

The Company has plans to access additional capital to meet its obligations for the twelve months from the date these financial statements are available to be issued. Historically, the Company has raised additional equity and debt financing to fund its expansion; refer to Note 15 — Notes Payable and Line of Credit. The Company has also funded some of its capital expenditures through long-term financing with lenders and other investors as also described in further detail in Note 15 — Notes Payable and Line of Credit and Note 19 – Subsequent Events. Our ability to raise the additional capital is dependent on a number of factors, including, but not limited to, the market demand for our common stock, which itself is subject to a number of business risks and uncertainties, our creditworthiness and the uncertainty that we would be able to raise such additional capital at a price that is favorable to us. As of March 31, 2022, the Company has an effective S-3 shelf registration statement with $112.0 million of aggregate offering value available for the issuance of various types of securities, including common stock, preferred stock, debt securities and/or warrants. While management will look to continue funding future acquisitions, organic growth initiatives and continuing operations by raising additional capital from sources such as sales of its debt or equity securities or notes payable in order to meet operating cash requirements, there is no assurance that management’s plans will be successful.

As the Company continues its progression to build a full-service infrastructure services platform, a successful transition to attaining profitable operations is dependent upon achieving a level of positive cash flows through generating adequate revenue growth to support the Company’s cost structure. For the three months ended March 31, 2022, our revenues have increased by $64.7 million resulting in over a 1,100% increase in revenue compared to the three-month period ended in 2021. The significant increase in revenues during the year was primarily driven by the strategic acquisitions of Front Line Power Construction, LLC, Gibson Technical Services, IMMCO, Inc., and Full Moon Telecom, LLC made coupled with organic growth within Orbital Power Systems. In addition, two large utility scale solar projects were awarded to Orbital Solar Systems during the twelve-month period ended December 31, 2021. We anticipate, based on currently proposed plans and assumptions relating to our operations, the Company to generate sufficient revenue growth required to achieve profitability and generate positive cash flows from operations over the next twelve months. No assurance can be made that we will be able to obtain profitability and positive cash flows from our continuing operations.

The Company plans to meet its obligations as they become due over the next twelve months by raising additional capital through equity and debt financing sources and expected positive cash flows generated from operations. Given the considerations, we believe the mitigating effect of management’s plans has alleviated any substantial doubt about the Company’s ability to continue as a going concern.

Goodwill

The Company has Goodwill from acquisitions made in 2020, 2021 and 2022.

The Company tests for impairment of Indefinite-lived intangibles and Goodwill in the second quarter of each year and when events or circumstances indicate that the carrying amount of Goodwill exceeds its fair value and may not be recoverable. 

Under current accounting guidance, Orbital Energy Group is not required to calculate the fair value of a reporting unit unless the entity determines, based on a qualitative assessment, that it is more likely than not that its fair value is less than its carrying amount. The guidance includes a number of factors to consider in conducting the qualitative assessment. The Company tests for goodwill impairment in the second quarter of each year and whenever events or changes in circumstances indicate that the carrying amount of the asset exceeds its fair value and may not be recoverable.

To complete the review, management evaluated the fair value of the Goodwill and considered all known events and circumstances that might trigger an impairment of goodwill. We evaluated the OSS, FLP and GTS reporting units for possible triggering events of possible impairment as of the end of the quarter ended March 31, 2022, noting none. 

Accrued expenses

Accrued expenses are liabilities that reflect expenses on the statement of operations that have not been paid or recorded in accounts payable at the end of the period. At March 31, 2022 and  December 31, 2021, accrued expenses of $30.5 million and $28.3 million, respectively included the following components:

COVID-19 Assessment and Liquidity

In March 2020, the World Health Organization categorized the current coronavirus disease (“COVID-19”) as a pandemic, and the President of the United States declared the COVID-19 outbreak a national emergency. COVID-19 continues to spread throughout the United States and other countries across the world, and the duration and severity of its effects can be severe. While the Company expects the effects of the pandemic to negatively impact its results from operations, cash flows and financial position, the current level of uncertainty over the economic and operational impacts of COVID-19 means the related financial impact cannot be reasonably estimated at this time. The Company has experienced customer delays and extensions for projects, supply chain delays, furloughs of personnel, increased utilization of telework, increased safety protocols to address COVID-19 risks, decreased field service work and other impacts from the COVID-19 pandemic.  While the economic effects of COVID-19 are beginning to subside as a higher percentage of people become vaccinated, there remains uncertainty regarding the future affects of the pandemic. Events and changes in circumstances arising after March 31, 2022, including those resulting from the impacts of COVID-19, will be reflected in management’s estimates for future periods.

Management believes the Company's present cash flows along with access to additional debt and equity raises will allow OEG to meet its obligations for twelve months from the date these financial statements are available to be issued. Including our cash balance, we continue to manage working capital primarily related to trade accounts receivable, notes receivable, prepaid assets, contract assets and our inventory less current liabilities that we will manage during the next twelve months. In 2022, the Company has entered into various long and short-term debt agreements. Considering these above factors, management believes the Company can meet its obligations for the twelve-month period from the date the financial statements are available to be issued. 

The Company’s available capital may be consumed faster than anticipated due to other events, including the length and severity of the global novel coronavirus disease pandemic and measures taken to control the spread of COVID-19, as well as changes in and progress of our development activities and the impact of commercialization efforts due to the COVID-19 pandemic. The Company may seek to obtain additional capital as needed through equity financings, debt or other financing arrangements, but given the impact of COVID-19 on the U.S. and global financial markets, the Company may be unable to access further equity or debt financing when needed. As such, there can be no assurance that the Company will be able to raise additional capital when needed or under acceptable terms, if at all. The sale of additional equity may dilute existing shareholders and newly issued shares may contain senior rights and preferences compared to currently outstanding common shares.

Our significant accounting policies are detailed in "Note 2 Summary of Significant Accounting Policies" within Item 8 of the Company's Annual Report on Form 10-K for the year ended  December 31, 2021 filed with the SEC on March 31, 2022.

As part of the Company’s stated strategy to transform Orbital Energy Group into a diversified energy infrastructure services platform serving North American energy customers, the Company’s board of directors made the decision to divest of its Orbital Gas subsidiaries. The Orbital Gas subsidiaries provide proprietary gas measurement and sampling technologies and the integration of process control and measuring/sampling systems. They are legacy businesses that are not part of the Company’s strategy of building an infrastructure services company serving the electric power, telecommunications and renewable markets. The disposition of the Orbital Gas subsidiaries will facilitate the Company’s restructuring and cost savings initiatives and are intended to realign and simplify its business structure and better position the Company for future growth and improved profitability. In the fourth quarter the Company recorded a $9.2 million impairment related to its U.K. operations to write the value of its investment in the U.K. operations to its expected realizable value of 3 million GBP ($4.1 million on December 31, 2021).

The sale of the U.K. operations closed in May of 2022. Assets and liabilities held for sale are included in the Company's balance sheet and are described below. See Note 19. Subsequent Events for more information on the sale of the U.K. business. 

Selected data for these discontinued businesses consisted of the following:

Reconciliation of the Major Classes of Line Items Constituting Pretax Income from

Discontinued Operations to the After-Tax Income from Discontinued Operations That Are

Presented in the Condensed Consolidated Statement of Operations

(Unaudited)

There was $10 thousand net cash used in investing activities of discontinued operations for the three months ended March 31, 2022.

The Electric Power segment provides full service building, maintenance and support to the electrical power distribution, transmission, substation, and emergency response sectors of North America through Front Line Power, Orbital Power Services and  Eclipse Foundation. The Telecommunications segment composed of Gibson Technical Services and subsidiaries provides technical implementation, design, maintenance, emergency and repair support services in the broadband, wireless, and outside plant and building technologies.  The Renewables segment, Orbital Solar Services, provides engineering, procurement and construction (“EPC”) services that support the development of renewable energy generation focused on utility scale solar and community solar construction.

For our construction contracts, revenue is generally recognized over time. Our fixed price and unit-price construction projects generally use a cost-to-cost input method or an output method to measure our progress towards complete satisfaction of the performance obligation as we believe it best depicts the transfer of control to the customer. Under the cost-to-cost measure of progress, the extent of progress towards completion is measured based on the ratio of costs incurred to date to the total estimated costs at completion of the performance obligation. Under the output method, progress towards completion is measured based on units of work completed based on the contractual pricing amounts.  Under the output method, revenue is determined by actual work achieved. For jobs under the output method, revenue is earned based on each unit in the contract completed. We construct comprehensive revenue calculations based on quantifiable measures of actual units completed multiplied by the agreed upon contract prices per item completed. Revenue is also generally recognized over time as the customer simultaneously receives and consumes the benefits of our performance as we perform the service.

The timing of revenue recognition also depends on the payment terms of the contract, as our performance does not create an asset with an alternative use to us. For those contracts where the Company's performance creates or enhances an asset that the customer controls as the asset is created or enhanced or for which we have a right to payment for performance completed to date at all times throughout our performance, inclusive of a cancellation, we recognize revenue over time. As discussed above, these performance obligations use a cost-to-cost input method or output method to measure our progress towards complete satisfaction of the performance obligation as we believe it best depicts the transfer of control to the customer. However, for those contracts for which we do not have a right, at all times, to payment for performance completed to date and we are not enhancing a customer-controlled asset, we recognize revenue at the point in time when control is transferred to the customer. 

For our service contracts, revenue is also generally recognized over time as the customer simultaneously receives and consumes the benefits of our performance as we perform the service. For our fixed price service contracts with specified service periods, revenue is generally recognized on a straight-line basis over such service period when our inputs are expended evenly, and the customer receives and consumes the benefits of our performance throughout the contract term.

For certain of our revenue streams, such as call-out repair and service work, and outage services, that are performed under time and materials contracts, our progress towards complete satisfaction of such performance obligations is measured using an input method as the customer receives and consumes the benefits of our performance completed to date.

Due to uncertainties inherent in the estimation process, it is possible that estimates of costs to complete a performance obligation will be revised in the near-term. For those performance obligations for which revenue is recognized using a cost-to-cost input method, changes in total estimated costs, and related progress towards complete satisfaction of the performance obligation, are recognized on a cumulative catch-up basis in the period in which the revisions to the estimates are made. When the current estimate of total costs for a performance obligation indicates a loss, a provision for the entire estimated loss on the unsatisfied performance obligation is made in the period in which the loss becomes evident.

Accounts Receivable, Contract Assets and Contract Liabilities

Accounts receivable are recognized in the period when our right to consideration is unconditional. We also assess our customer's ability and intention to pay, which is based on a variety of factors, including our historical payment experience with and the financial condition of our customers.

The timing of revenue recognition may differ from the timing of invoicing to customers. Contract assets include unbilled amounts from our construction projects when revenue recognized under the output method or input cost-to-cost method exceed the amounts invoiced to our customers, as the amounts cannot be billed under the terms of our contracts. Such amounts are recoverable from our customers based upon various measures of performance, including achievement of certain milestones, completion of specified units or completion of a contract. Also included in contract assets are retainage receivables and amounts we seek or will seek to collect from customers or others for errors or changes in contract specifications or design, contract change orders or modifications in dispute or unapproved as to both scope and/or price or other customer-related causes of unanticipated additional contract costs (claims and unapproved change orders). Our contract assets do not include capitalized costs to obtain and fulfill a contract. Contract assets are generally classified as current within the Condensed Consolidated Balance Sheets.

Contract liabilities from our construction contracts occur when amounts invoiced to our customers exceed revenues recognized under the cost-to-cost or output method measure of progress. Contract liabilities additionally include advanced payments from our customers on certain contracts and provision for future contract losses for those contracts estimated to close in a gross loss position. Contract liabilities decrease as we recognize revenue from the satisfaction of the related performance obligation and are recorded as either current or long-term, depending upon when we expect to recognize such revenue.

Balances and activity in the current contract liabilities as of and for the three months ended March 31, 2022 and 2021 was as follows:

Performance Obligations

Remaining Performance Obligations

Remaining performance obligations represents the transaction price of contracts with customers for which work has not been performed and excludes unexercised contract options and potential orders under ordering-type contracts. As of March 31, 2022, the Company's remaining performance obligations are generally expected to be filled within the next 12 months. For the contracts that are greater than 12 months the Company has approximately $261.2 million in the aggregate of future revenue related to remaining performance obligations that are unsatisfied or partially unsatisfied as of  March 31, 2022. 

Any adjustments to net revenues, cost of revenues, and the related impact to operating income are recognized as necessary in the period they become known. These adjustments may result from positive program performance, and may result in an increase in operating income during the performance of individual performance obligations, if we determine we will be successful in mitigating risks surrounding the technical, schedule and cost aspects of those performance obligations. Likewise, these adjustments may result in a decrease in operating income if we determine we will not be successful in mitigating these risks. Changes in estimates of net revenues, cost of revenues and the related impact to operating income are recognized on a cumulative catch-up basis in the period they become known, which recognizes in the current period the cumulative effect of the changes on current and prior periods based on a performance obligation's percentage of completion. A significant change in one or more of these estimates could affect the profitability of one or more of our performance obligations. For separately priced extended warranty or product maintenance performance obligations, when estimates of total costs to be incurred on the performance obligation exceed total estimates of revenue to be earned, a provision for the entire loss on the performance obligation is recognized in the period the loss is determined.

Performance Obligations Satisfied Over Time

To determine the proper revenue recognition method for our contracts, we evaluate whether a single contract should be accounted for as more than one performance obligation. This evaluation requires significant judgment and the decision to separate the single contract into multiple performance obligations could change the amount of revenue and profit recorded in a given period.

For most of our contracts, the customer contracts with us to provide a significant service of integrating a complex set of tasks and components into a single project or capability (even if that single project results in the delivery of multiple units). Hence, the entire contract is accounted for as one performance obligation. Less commonly, however, we may promise to provide distinct goods or services within a contract in which case we separate the contract into more than one performance obligation. If a contract is separated into more than one performance obligation, we allocate the total transaction price to each performance obligation in an amount based on the estimated relative standalone selling prices of the promised goods or services underlying each performance obligation. We infrequently sell standard products with observable standalone sales. In cases where we do, the observable standalone sales are used to determine the standalone selling price. More frequently, we sell a customized customer specific solution, and in these cases we typically use output method or the expected cost plus a margin approach to estimate the standalone selling price of each performance obligation.

Variable Consideration

The nature of our contracts gives rise to several types of variable consideration. In rare instances, we include in our contract estimates, additional revenue for submitted contract modifications or claims against the customer when we believe we have an enforceable right to the modification or claim, the amount can be estimated reliably and its realization is probable. In evaluating these criteria, we consider the contractual/legal basis for the claim, the cause of any additional costs incurred, the reasonableness of those costs and the objective evidence available to support the claim. These amounts are included in our calculation of net revenue recorded for our contracts and the associated remaining performance obligations. Additionally, if the contract has a provision for liquidated damages in the case that the Company misses a timing target, or fails to meet any other contract benchmarks, the Company accounts for those estimated liquidated damages as variable consideration and will adjust revenue accordingly with periodic updates to the estimated variable consideration as the job progresses. Liquidated damages are recognized as variable consideration and are estimated based on the most likely amount that is deemed probable of realization.

Significant Judgments

Our contracts with certain customers may be subject to contract cancellation clauses. Contracts with other cancellation provisions may require judgment in determining the contract term, including the existence of material rights, transaction price and identifying the performance obligations and whether a contract should be accounted for over time or on a completed contract basis. Revenue is recognized for certain projects over time using cost-based input methods, in which significant judgement is required to evaluate assumptions including the amount of total estimated costs to determine our progress towards contract completion and to calculate the corresponding amount of revenue to recognize.

At times, customers may request changes that either amend, replace or cancel existing contracts. Judgment is required to determine whether the specific facts and circumstances within the contracts require the changes to be accounted for as a separate contract or as a modification. Generally, contract modifications containing additional goods and services that are determined to be distinct and sold at their stand-alone selling price are accounted for as a separate contract. For contract modifications where goods and services are not determined to be distinct and sold at their stand-alone selling price, the original contract is updated and the required adjustments to revenue and contract assets, liabilities, and other accounts will be made accordingly.

Our contracts with customers often include promises to transfer multiple products and services to a customer. Determining whether products and services are considered distinct performance obligations that should be accounted for separately rather than together may require significant judgment. For, example, we consider many of our contracts that coordinate multiple products into an integrated system to be a single performance obligation, while the same products would be considered separate performance obligations if not so integrated.

In contracts where there are timing differences between when we transfer a promised good or service to the customer and when the customer pays for that good or service, we have determined that, our contracts do not include a significant financing component.

The following tables present the Company's revenues disaggregated by the type of customer:

The following tables present the Company's revenues disaggregated by type of contract:

Inventories consist of work-in-process and finished goods and are stated at the lower of cost or net realizable value using the first-in, first-out (FIFO) method as a cost flow convention or through the moving average cost method. At March 31, 2022 and December 31, 2021, inventory by category is valued net of reserves and consists of:

The Company has a minority ownership in Virtual Power Systems ("VPS"). The VPS investment basis at March 31, 2022 and December 31, 2021 was $1.1 million and $1.1 million, respectively, as reflected on the condensed consolidated balance sheets. The investment is held at March 31, 2022 under the cost method of accounting for investments. 

Consolidated total operating lease costs were $1.8 million for the three months ended March 31, 2022 and $0.7 million for the three months ended March 31, 2021 and are included in cost of sales; selling, general and administrative expense; and other income (expense), on the condensed consolidated statement of operations.

Future minimum operating lease obligations at March 31, 2022 are as follows for the years ended December 31:

Total lease cost and other lease information is as follows:

Variable lease costs primarily include common area maintenance costs, real estate taxes and insurance costs passed through to the Company from lessors.

Future minimum finance lease obligations are as follows:

Total financing lease costs are as follows:

Through December 31, 2021, the Company had been vesting a series of stock appreciation rights (SARS) to be settled in cash to certain executives. The SARS were considered liability-classified awards meaning their fair-values were remeasured at the end of each reporting period using a binomial lattice model and any changes in fair value for the vesting periods to-date were recorded through the income statement with a corresponding liability accrued on the balance sheet. Since December 31, 2021, the SARS have been exchanged for restricted stock units (RSUs) on the modification date of January 14, 2022 as approved by the Board of Directors. To account for this exchange, the company revalued the SARS as of the modification date of January 14, 2022 using the binomial lattice model and recorded changes in the vested value since December 31, 2021 as an adjustment to the income statement. The Company then reclassified the SARS accrued liability to APIC for new RSUs and recognized incremental expense. Shares deemed vested at the modification date were released and issued net of tax in March 2022. The company recorded expense for these RSUs for the period of January 15, 2022 to March 31, 2022.

Restricted Stock

In  March 2021, the Company granted 3 million restricted shares with an aggregate fair value of $16.4 million with a graded vesting schedule. One-third of which were vested in  April 2021, one-third of which were due to vest in  April 2022, and one-third of which were due to vest in  April 2023. The Company recorded a net credit of $3.9 million and expense of $2.0 million to compensation expense related to the forfeiture and partial vesting of these grants in the three months ended March 31, 2022 and March 31, 2021, respectively. The credit to compensation expense in the first three months of 2022 was due to a $5.2 million dollar reversal of expense related to the forfeiture of the restricted stock upon the termination of an employee as of March 31, 2022. 

Operating segments are defined in accordance with ASC 280-10 as components of an enterprise for which separate financial information is available that is evaluated regularly by the chief operating decision maker, or decision-making group, in deciding how to allocate resources and in assessing performance. The measurement basis of segment profit or loss is income (loss) from operations. Management has identified five operating segments based on the activities of the Company in accordance with ASC 280-10. These operating segments have been aggregated into three reportable segments. The three reportable segments are Electric Power, Telecommunications, and Renewables and an Other category. 

The Electric Power segment consists of Front Line Power Construction, LLC, Orbital Power Services, and Eclipse Foundation Group. The segment provides comprehensive solutions to customers in the electric power industries. 

The Telecommunications segment is made up of Gibson Technical Services, Inc. (“GTS”) (acquired  April 13, 2021). GTS is an Atlanta-based telecommunications company providing diversified telecommunications services nationally since 1990 and is the parent of the following companies: IMMCO, Inc., Full Moon Telecom, and Coax Fiber Solutions, LLC.

The Renewables segment consists of Orbital Solar Services based in Raleigh, North Carolina. Orbital Solar Services provides engineering, procurement and construction (“EPC”) services that support the development of renewable energy generation focused on utility-scale solar construction. The Company serves a wide variety of project types, including commercial, substation, solar farms and public utility projects.

The Other category is made up primarily of the Company's corporate activities. This category does not include any operating segments and does not generate revenue. 

The following information represents segment activity for the three months ended March 31, 2022:

⁽¹⁾For the Electric Power segment and the Telecommunications segment, depreciation and amortization includes $3.2 million and $0.2 million respectively, which was included in cost of revenues in the Condensed Consolidated Statements of Operations.

⁽²⁾  Includes purchases of property, plant and equipment and other intangible assets. The Other category includes expenditures for discontinued operations of $10 thousand.

The following information represents selected balance sheet items by segment as of March 31, 2022:

The following information represents segment activity for the three months ended March 31, 2021:

⁽¹⁾ For the Electric Power segment, depreciation and amortization includes $0.2 million, which was included in cost of revenues in the Condensed Consolidated Statements of Operations. Other category includes $432 thousand of depreciation and amortization from discontinued operations.

⁽²⁾  Includes purchases of property, plant and equipment and other intangible assets. The Other category includes expenditures for discontinued operations of $705 thousand.

The following information represents selected balance sheet items by segment as of December 31, 2021:

On October 28, 2021, the Financial Accounting Standards Board ("FASB") issued Accounting Standards Update ("ASU") 2021-08, Business Combinations (Topic 805): Accounting for Contract Assets and Contract Liabilities from Contracts with Customers. This guidance will require entities to apply Topic 606 to recognize and measure contract assets and contract liabilities in a business combination. This standard was designed to provide consistent recognition and measurement guidance for revenue contracts with customers. Legacy guidance requires entities to record contract assets and contract liabilities acquired to be recorded at fair value. The amendments will be effective for the Company beginning for fiscal years beginning after December 15, 2022. Early adoption is allowed. If an entity early adopts, the entity would be required to apply the new guidance to all acquisitions made in the year of the early adoption. The Company is still reviewing the standard and as of the reporting date of this filing has not elected to early adopt.

The Company’s fair value hierarchy for our financial assets and liabilities as of March 31, 2022 and December 31, 2021 was as follows:

There were no transfers between Level 3 and Level 2 in the three months ended March 31, 2022 as determined at the end of the reporting period.

In accordance with Financial Accounting Standards Board ("FASB") Accounting Standards Codification Topic 260 (“FASB ASC 260”), “Earnings per Share,” Basic loss from continuing operations per share, basic income from discontinued operations per share and basic net income (loss) per share that is available to shareholders is computed by dividing the income or loss by the weighted average number of common shares outstanding during the period. Diluted net loss per share is computed by dividing the respective loss available to common stockholders by the weighted average number of diluted shares outstanding during the period calculated using the treasury stock method. Due to the Company’s loss from continuing operations in the three months ended March 31, 2022 and March 31, 2021, the assumed exercise of stock options and the unvested restricted stock that would otherwise increase diluted shares using the treasury stock method would have had an antidilutive effect and therefore 0.2 million shares related to stock options outstanding at March 31, 2022 and zero shares of restricted stock were excluded from the computation of diluted net loss per share for the three months ended March 31, 2022 and 0.2 million shares related to stock options outstanding at March 31, 2021 were excluded for the three months ended March 31, 2021 and 3.0 million shares of restricted stock were excluded from the computation of diluted net loss per share for the three months ended March 31, 2021. Accordingly, diluted earnings (loss) per share for continuing operations, discontinued operations and net income is the same as basic earnings (loss) per share for continuing operations, discontinued operations and net income for the three months ended March 31, 2022 and 2021.

The Company is subject to taxation in the U.S., as well as various state and foreign jurisdictions. The Company continues to record a full valuation allowance against the Company's U.S. and U.K. net deferred tax assets and a partial valuation allowance on its Canada deferred tax assets as it is not more likely than not that the Company will realize a benefit from these assets in a future period other than a $98 thousand carryback benefit at Canada. In future periods, tax benefits and related deferred tax assets will be recognized when management concludes realization of such amounts is more likely than not. 

Total net income tax expense of $0.2 million and $16 thousand were recorded to the income tax provision from continuing operations for the three months ended March 31, 2022 and March 31, 2021, respectively, resulting in an effective tax rate of (0.7%) and (0.1%), respectively. Income tax expense was primarily due to state minimum taxes and estimated Texas gross receipts taxes.

Line of Credit

On August 19, 2021, the Company's GTS subsidiary entered into a $4.0 million variable rate line of credit agreement. Interest accrues at a rate of 2.05% over the Daily Simple Secured Overnight Financing Rate ("SOFR") index rate. At March 31, 2022 the Company had an outstanding balance on the line of credit of $4.0 million with zero dollars available for borrowing.

Debt Modifications

In the first quarter of 2022, the Company entered into a loan modification on the Front Line Seller Financed notes payable. In order to extend the maturity date of these loans from the original maturity date of May 16, 2022, the Company agreed to reduce the restriction period on the stock granted to the sellers from two years to one and guarantee a $4.00 stock value upon the expiration of the restriction period. The stock price guarantee was valued as a put option and the additional expected cost of the debt from the put option was determined to be an extinguishment of debt and for this transaction, the Company recorded a $25.3 million loss on extinguishment. The put option was valued at $25.9 million and the difference between the put option value and the discount on the orginal and amended seller notes was recorded as a loss on extingusihment. The put option was valued as of the March 29, 2022 modification date. Between the inception date and the quarter-end date of March 31, 2022, the Company's stock fluctuated by $.01 and the Company determined that any revaluation of the put option for a change in value during those three days would be immaterial. 

The Company’s major product lines in 2021 and 2022 were electric power transmission and distribution maintenance and service, utility-scale solar construction projects and telecommunications maintenance and service.

The Company had the following revenue concentrations by customer greater than 10% of consolidated revenue:

The Company did not have geographic revenue concentrations outside the U.S.A. greater than 10% of consolidated revenue.

The Company had the following gross trade accounts receivable concentrations by customer greater than 10% of gross trade accounts receivable:

The Company did not have a geographic concentrations of gross trade accounts receivable outside of the U.S.A. greater than 10% of gross trade accounts receivable.

The Company had one supplier concentration of approximately 12% for the three months ended March 31, 2022 in the Renewables segment and one supplier concentration of approximately 12% in the three months ended March 31, 2021 in the Electric Power segment.

Acquisition of Coax Fiber Solutions

Effective March 7, 2022, GTS, an OEG subsidiary, entered into a share purchase agreement to acquire Coax Fiber Solutions (CFS), a Georgia based GDOT Certified contractor specializing in Aerial Installation, directional drilling, trenching, plowing, and missile crews for telecommunications, power, gas, water, CCTV, ATMS, and traffic signal cable installation. GTS paid $0.8 million and are to issue 125,000 shares of restricted common stock to the Seller to purchase CFS with the stock preliminarily vaued at $250,000. Goodwill reflects the excess purchase price over the fair value of net assets. The Company recorded preliminary opening balance items of $0.4 million of current assets, $0.5 million of fixed assets, $1.4 million of goodwill, and $1.3 million of liabilities as part of this transaction. The company is currently in the process of finalizing the allocation of the purchase price for this acquisition.

Off-Balance Sheet Arrangements

Performance and Payment Bonds and Parent Guarantees

In the ordinary course of business, Orbital Energy Group and its subsidiaries are required by certain customers to provide performance and payment bonds for contractual commitments related to its projects. These bonds provide a guarantee to the customer that the Company will perform under the terms of a contract and that the Company will pay its subcontractors and vendors. If the Company fails to perform under a contract or to pay its subcontractors and vendors, the customer may demand that the surety make payments or provide services under the bond. The Company must reimburse the surety for expenses or outlays it incurs. Certain bonds are for open-ended contracts with multiple work orders so the value may increase as the work progresses and more work orders are started. The bonds will remain in place as the Company completes projects and resolves any disputed matters with the customers, vendors and subcontractors related to the bonded projects. As of March 31, 2022 the total amount of the outstanding performance and payment bonds was approximately $108.1 million. In addition, the Company had letters of credit outstanding of $1.4 million as of March 31, 2022.

Additionally, from time to time, we guarantee certain obligations and liabilities of our subsidiaries that may arise in connection with, among other things, contracts with customers, equipment lease obligations, and contractor licenses. These guarantees may cover all of the subsidiary’s unperformed, undischarged and unreleased obligations and liabilities under or in connection with the relevant agreement. For example, with respect to customer contracts, a guarantee may cover a variety of obligations and liabilities arising during the ordinary course of the subsidiary’s business or operations, including, among other things, warranty and breach of contract claims, third-party and environmental liabilities arising from the subsidiary’s work and for which it is responsible, liquidated damages, or indemnity claims.